Case Information
*0 FILED IN 3rd COURT OF APPEALS AUSTIN, TEXAS 3/31/2015 1:17:23 PM JEFFREY D. KYLE Clerk NO. 03-14-00821-CV THIRD COURT OF APPEALS 3/31/2015 1:17:23 PM JEFFREY D. KYLE 03-14-00821-CV AUSTIN, TEXAS *1 ACCEPTED [4710355] CLERK IN THE TRIAL COURT OF APPEALS THIRD DISTRICT OF TEXAS AUSTIN, TEXAS
__________________________________________________________________
DUONG NHU HA AND D&H RESTAURANT EQUIPMENT Appellants
vs. HUNAN RANCH CORPORATION Appellee
On appeal from the 201st Judicial District Of Travis County, Texas
APPELLEE’S RESPONSE TO APPELLANT’S BRIEF __________________________________________________________________
Doran D. Peters State Bar No. 24027615 service@legalstrategy.com Teresa C. Baker State Bar No. 24053131 service@legalstrategy.com HAJJAR PETERS LLP 3144 Bee Caves Rd.
Austin, Texas 78746 Telephone: (512) 637-4956 Facsimile: (512) 637-4958 ATTORNEYS FOR APPELLEE Dated: March 30, 2015 *2
IDENTITY OF PARTIES AND COUNSEL Appellants: Duong Nhu Ha and D&H Restaurant Equipment
Attorney for Appellants: Frank C. Brame
State Bar No. 24031874 VINSON & ELKINS LLP 2001 Ross Ave. Suite 3700 Dallas, Texas 75201 Telephone: (214) 220-7818 Facsimile: (214) 999-7818 fbrame@velaw.com Janice L. Ta
State Bar No. 24075138 Michelle Arishita
State Bar No. 24092048 VINSON & ELKINS LLP 2801 Via Fortuna, Suite 100 Austin, Texas 78746 Telephone: (512) 578-8402 Facsimile: (512) 236-8239 jta@velaw.com
marishita@velaw.com Appellee: Hunan Ranch Corporation
Attorney for Appellee: Trial and Appellate Counsel:
Doran D. Peters
State Bar No. 24053131 Teresa C. Baker
State Bar No. 24053131 HAJJAR PETERS, LLP 3144 Bee Caves Road Austin, Texas 78746 Telephone: (512) 637-4956 Facsimile: (512) 637-4958 service@legalstrategy.com ii *3 TABLE OF CONTENTS
IDENTITY OF PARTIES AND COUNSEL .......................................................... ii
TABLE OF CONTENTS .................................................................................iii
INDEX OF AUTHORITIES ............................................................................. v
STATEMENT OF THE CASE .......................................................................... 1
ORAL ARGUMENT UNNECESSARY ............................................................... 1
ISSUES PRESENTED ..................................................................................... 1
STATEMENT OF FACTS ............................................................................... 2
SUMMARY OF THE ARGUMENT ................................................................... 5
ARGUMENT ............................................................................................... 5
Reply to Issue 1: Appellants have not satisfied the preliminary requirements for a restricted appeal ................................................................. 5 Reply to Issue 2: There is no error on the face of the record as Hunan Ranch provided sufficient evidence to support the default judgment and there is no requirement of a court reporter’s record ................ 6 Reply to Issue 3: There is no error on the face of the record as Hunan Ranch provided sufficient evidence, including an affidavit from Hunan Ranch owner, to support its damages ....................................... 8 Reply to Issue 4: There is no error on the face of the record as the certified record, including pleadings and evidence, provided a causal nexus between Hunan Ranch’s claims and its damages ................... 9 Reply to Issue 5: Hunan Ranch proved its damages and therefore is entitled to the awarded attorney’s fees .................................................. 12 PRAYER ................................................................................................... 13 iii
CERTIFICATE OF COMPLIANCE .................................................................. 14
CERTIFICATE OF SERVICE .......................................................................... 14 iv
INDEX OF AUTHORITIES
CASES
Fleming Mfg. Co. V. Capitol Brock, Inc. , 734 S.W.2d 405, 409
(Tex. App.--Austin 1987, writ ref’d n.r.e ............................................................ 8
Holt Atherton Indus., Inc. v. Heine , 835 S.W.2d 80, 84, 35
Tex. Sup. Ct. J. 881 (Tex. 1992) ...................................................................... 7
Morgan v. Compugraphic Corp. , 675 S.W.2d 729, 732 (Tex. 1984) ................... 6, 8, 10, 11
Norman Commc’ns v. Tex. Eastman Co ., 955 S.W.2d 269 270 (Tex. 1997) ........................ 5
S outhwest Battery Corp. v. Owen , 131 Tex. 423, 115 S.W.2d 1097 (Tex. 1938) ................. 7
Stone v. Talbert Operations, LLC, No. 04-14-00008-CV,
2014 Tex. App. LEXIS 13870, at *1-2.
(Tex. App.—San Antonio, Dec. 31, 2014, no pet.). ............................................... 6
Tex. Commerce Bank, N.A. v. New , 3 S.W.3d 515, 516-517 (Tex. 1999) ....................... 6, 7
Whitaker v. Rose , 218 S.W.3d 216, 220
(Tex. App. –Houston [14th Dist.] 2007, no pet.) ........................................... 7, 8, 11
STATUTES AND RULES
T EX . C IV . P RAC . & R EM . C ODE A NN . § 38.001 ...................................................... 10
T EX . R. C IV . P. 243 ...................................................................................... 11
T EX R. A PP . P. 30 .......................................................................................... 5 v
STATEMENT OF THE CASE
Nature of the Case: This is a restricted appeal in which appellants, Duong Nhu Ha
and D&H Restaurant Equipment appeal a default judgment that was granted by the 201 st Judicial District Court of Travis County, Texas.
Course of
Proceedings: Hunan Ranch Corporation sued Ha Duong Nhu and D&H
Restaurant Equipment for breach of contract. CR 1-3. On June 30, 2014, Judge Suzanne Covington conducted a bench trial on liability and damages. Judge Covington granted the default judgment against Ha Duong Nhu and D&H Equipment. CR 9- 11.
Trial Court: 201st Judicial District Court of Travis County, Texas.
ORAL ARGUMENT UNNECESSARY The dispositive issues in this case are unremarkable and controlled by well settled law. The briefs and the record in this case adequately present the facts and legal arguments
and, because of the foregoing, oral argument will not aid the Court in its decision on this
case. However, if the Court determines oral argument to be appropriate, Appellee will
appear and participate.
ISSUES PRESENTED
Reply to Issue 1: Appellants have not satisfied the preliminary requirements for a restricted appeal.
Reply to Issue 2: There is no error on the face of the record as Hunan Ranch provided sufficient evidence to support the default judgment and there is no requirement of a court reporter’s record.
Reply to Issue 3: There is no error on the face of the record as Hunan Ranch provided sufficient evidence, including an affidavit from Hunan Ranch owner, to support its damages.
Reply to Issue 4: There is no error on the face of the record as the certified record, including pleadings and evidence, provided a causal nexus between Hunan Ranch’s claims and its damages.
Reply to Issue 5: Hunan Ranch proved its damages and therefore is entitled to the awarded attorney’s fees.
STATEMENT OF FACTS
First and foremost, Appellee disagrees with some of the statements included in Appellant’s “Statement of Facts.” Appellant includes “facts” which are nowhere in the
certified record. Although, Appellants cite to several portions of the record in connection
with its presentation of facts, these cited portions do not actually support Appellants’
statements. These unsupported “facts” are pointed out and discussed below.
In November of 2013, parties [1] entered into an agreement whereby Defendants would manufacture and install a commercial wok at Appellee’s restaurant. (Certified
Record “CR” 2 and 17). The wok that was to be provided by Appellants was to replace the
existing wok at Appellee’s restaurant. (CR 2 and 17). All parties were aware that the wok
was critical to the operation of Appellee’s restaurant. (CR 2, 17-18). Parties agreed that the
new wok would be completed and installed no later than December 26, 2013. (CR 2, 18).
Appellee followed-up with Appellants on or about December 19, 2013, to confirm that the new wok would be ready for installation by December 26, 2013. (CR 18).
*8 However, during this conversation, Appellee was informed that there was a delay and the
new wok would not be ready until January 8, 2014. (CR-18). Appellants stated that the
parties agreed to delay delivery so that the installation of the new wok range would coincide
with some anticipated renovations at the restaurant, however, Appellants’ cite to the
certified record includes no such facts. (Appellants’ Brief pg. 3). On or about January 4,
2014, Appellee spoke with Appellants wherein Appellants confirmed that the new wok
would be ready for installation on January 8, 2014. (CR 18).
In order to perform renovations on Appellee’s restaurant, including installation of the new wok, Appellee closed its restaurant on January 6, 2014, with the intention of
reopening on January 9, 2014. (CR 18). Again, in Appellants’ Brief they disingenuously
include facts that are not in the record, and state that “Mr. Chen asked third-party
contractors to remove the old wok range in order to repair a wall; these contractors never
reinstalled the old wok range after the renovations were completed.” (Appellants’ Brief pg.
4). January 8, 2014, came and went with no wok delivered by Appellants. (CR 18).
Appellee contacted Appellants following the non-delivery and was told that the wok would
be ready on January 11, 2014. (CR 18). On January 11, 2014, Appellants again failed to
deliver the new wok and did not answer Appellee’s calls concerning the non-delivery of the
wok. (CR 18).
Appellants finally contacted Appellee on January 14, 2014, and reported that the new wok was still not ready. (CR 18). Due to the non-delivery of the new wok, Appellee
was forced to have Appellants install the old wok. (CR 18). On January 16, 2014,
Appellants installed the old wok and Appellee was able to open for dinner on January 17,
2014. (CR 18).
On or about February 18, 2014, Appellee corresponded with Appellants and requested that the new wok be delivered by February 20, 2014. (CR 18). Furthermore,
Appellee pointed out to Appellants that the failure to deliver and install the new wok caused
the Appellee thousands of dollars in damages. (CR 18). Appellants finally delivered the new
wok on March 28, 2014, more than 90 days after the expected delivery date. (CR 18). Here
again, in Appellants’ Brief they include the “facts” that Mr. Ha drove to Austin to install the
old commercial wok while the new one was being refurbished and that Mr. Ha worked
overnight to install the new wok. (Appellants’ Brief pg.4). Again, Appellants cite to the
record in an attempt to mislead the Court, but these “facts” are nowhere in the record.
Appellee sued Appellants for breach of contract. (CR 1-3). Appellants were served with citation and Plaintiff’s Original Petition on March 29, 2014. (CR 5-8). In Appellants’
Brief, they again insert unsupported facts concerning service of process and communications
surrounding same. (Appellants’ Brief pgs. 4-5). Appellants did not file an answer and on
June 30, 2014, a bench trial was held on liability and damages and a default judgment was
granted. (CR 9-11). The final judgment granted Appellee damages in the total amount of
$38,663.81, plus interest, as well as attorney’s fees in the amount of $6,693.75. (CR 9-10).
SUMMARY OF THE ARGUMENT The trial court correctly issued a default judgment against Appellants. In order to prevail on a restricted appeal, Appellants must be able to show that error is apparent on the
fact of the record. Appellants argue that there is lack of evidence to support the default
judgment, because of lack of exhibits and a court reports record. However, there is
sufficient evidence to support the default judgment in the pleadings, including the affidavit
of John Chen. Although Appellants cite to the affidavit of John Chen for support of their
“facts” on at least twelve (12) occasions throughout their Appellants’ Brief, they fail to
acknowledge that the affidavit is in fact sufficient evidence to support the no-answer default
judgment found by the trial court.
Appellee filed a lawsuit for breach of contract and damages. After Appellants were served and failed to file an answer, Appellee obtained a no-answer default judgment. The
judgment was based upon the pleadings and evidence, which are included in the certified
record. Accordingly, the trial court correctly found on liability and damages against
Appellants and properly granted the default judgment.
ARGUMENT
Reply to Issue 1: Appellants have not satisfied the preliminary requirements
for a restricted appeal. In order to prevail on their restricted appeal, Appellants are required to show the following: (1) they filed a notice of appeal within six months after the judgment was signed;
(2) they were a party to the underlying lawsuit; (3) they did not participate in the hearing
that resulted in the judgment complained or and did not timely file any post judgment
motions or requests for findings of fact and conclusions of law; and (4) the error about
which Appellants complain is apparent from the face of the record. Tex R. App. P. 30;
Norman Commc’ns v. Tex. Eastman Co ., 955 S.W.2d 269 270 (Tex. 1997).
Appellee agrees with Appellants that they have established the first three elements.
However, Appellee disagrees with Appellants that there is error apparent from the face of
the record. The error must appear on the face of the record. Id . As discussed in greater
detail below, there is sufficient evidence in the record to support a default judgment on
liability and damages, and therefore, the trial court was correct in issuing the final judgment.
Reply to Issue 2: There is no error on the face of the record as Hunan Ranch
provided sufficient evidence to support the default judgment and there is no requirement of a court reporter’s record.
Hunan Ranch presented evidence to support liability and damages, through the affidavit of Hunan Ranch owner John Chen. Appellants incorrectly states that Hunan Ranch
failed to present evidence to support the calculations of its unliquidated damages, because
certain exhibits were not entered into the record. What Appellants fail to address, is that the
affidavit evidence provides all the necessary evidence, with or without the exhibits.
Appellants are aware that the affidavit is included in the record, as they cite to it on
numerous occasions throughout their brief.
In our case, which is a no-answer default judgment, judgment can be entered on the pleadings alone, and all facts properly plead are deemed admitted. Morgan v. Compugraphic
Corp. , 675 S.W.2d 729, 732 (Tex. 1984). Defendant’s liability for all pleaded causes of
action is conclusively established and all allegations of fact in the petition, except the amount
of unliquidated damages, are deemed admitted. Id at 731-32. In the case of a no-answer
default judgment, a court may award damages based on affidavits . Tex. Commerce Bank, N.A.
v. New , 3 S.W.3d 515, 516-517 (Tex. 1999).
In the present case, Appellee establishes allegations of fact in its Original Petition, and subsequently establishes unliquidated damages in the Affidavit of John Chen. (CR 1-3,
17-19). Appellants never claim that the original petition or affidavit of John Chen is invalid
or not part of the record, they only state that the exhibits to the affidavit were not in the
record. The pleadings and the affidavit of John Chen include sufficient facts and testimony
on liability and damages, and therefore there is evidence in the record to support the trial
court’s judgment.
Appellant also erroneously argues, that there is error apparent on the face of the record because no reporter’s record was taken of the default judgment proceedings. In
support of their position, Appellants rely on Stone v. Talbert Operations, LLC , in which the
court held “error [was] apparent on the face of the record” because “no reporter’s record
was taken of the trial court’s evidentiary hearing resulting in the no-answer default
judgment.” No. 04-14-00008-CV, 2014 Tex. App. LEXIS 13870, at *1-2. (Tex. App.—
San Antonio, Dec. 31, 2014, no pet.). In Appellants’ Brief, they disingenuously represent to
the court that the Stone case has “similar facts” to our case, which is not true. Specifically,
unlike our case -- in which there is an affidavit, the Stone case had only the petition and no
affidavits.
Our case is distinguishable from Stone in that in our case an affidavit was entered into evidence and is in the certified record. (CR 17-19). In Whitaker v. Rose , Appellees provided
the trial court with affidavits in support of their damages. 218 S.W.3d 216, 220 (Tex App.
– Houston [14 th Dist.] 2007, no pet). The Court in Whitaker found that the lack of a
reporter’s record in an appeal from a no-answer default judgment does not constitute error
on the face of the record. Id. Similarly, in our case, John Chen provided an affidavit which
included sworn testimony on the breach of contract and damages. Therefore, no reporter’s
record of the default hearing was required as argued by Appellants.
Reply to Issue 3: There is no error on the face of the record as Hunan Ranch
provided sufficient evidence, including an affidavit from Hunan Ranch owner, to support its damages.
Through the affidavit of John Chen, Hunan Ranch provided sufficient evidence of damages. Recovery of lost profits does not require that the loss be susceptible to exact
calculations. Holt Atherton Indus., Inc. v. Heine , 835 S.W.2d 80, 84, 35 Tex. Sup. Ct. J. 881
(Tex. 1992). The amount of loss must be shown with reasonable certainty by competent
evidence. S outhwest Battery Corp. v. Owen , 131 Tex. 423, 115 S.W.2d 1097 (Tex. 1938).
Unliquidated damages can be proved up through an evidentiary hearing or with affidavits.
Texas Commerce Bank, Nat’l Ass’n , 3 S.W.3d at 515.
In our case, we have an affidavit from one of Appellee’s owners and directors. (CR 17-19) In this affidavit, he clearly establishes the timeline of Appellants’ breach and the effect
of Appellants’ breach. Specifically, through Appellee’s Original Petition and the affidavit of
John Chen, Appellee clearly establish that Appellants’ breach caused Appellee’s restaurant to
be closed for 8.5 days. (CR 1-3 and 17-19). Furthermore, competent evidence is provided
by John Chen, that the damages total $38,663.81. (CR 19). This was calculated on a per day
basis and is not excessive. (CR 19). Furthermore, the $670.00 in voids and credits due to the
faulty old wok is also competent evidence, established by the testimony of the owner of
Hunan Ranch. (CR 19).
Reply to Issue 4: There is no error on the face of the record as the certified
record, including pleadings and evidence, provided a causal nexus between Hunan Ranch’s claims and its damages.
Again, in Appellants arguments concerning the causal nexus, they continue to intentionally confuse the Court by citing to the record, wherein the information cited does
not exist. We will point this out during the course of Appellee’s argument.
In a no-answer default judgment, all facts properly plead are deemed admitted.
Morgan , 675 S.W.2d at 732; Whitaker , 218 S.W.3d at 220. If the facts set out in the petition
allege a cause of action, a default judgment conclusively establishes the defendant’s liability.
Morgan , 675 S.W.2d at 731. In Fleming Mfg. Co. V. Capitol Brock, Inc. , the court stated, “We
cannot on one hand articulate the rule that a party admits all factual allegations concerning
liability when he fails to answer, and then allow such a party to nonetheless contest its
liability on remand by arguing that the liability and damages issues are inextricably
intertwined.” 734 S.W.2d 405, 409 (Tex. App.--Austin 1987, writ ref’d n.r.e.). Appellee
properly plead in its Original Petition that there was an agreement between Appellee and
Appellants whereby Appellants would deliver and install a commercial wok at Plaintiff’s
restaurant. (CR 2). Appellee further plead that the wok was to replace the existing wok and
all parties knew that the wok was critical to the operation of Plaintiff’s restaurant. (CR 2).
Further, in its Original Petition, Appellee stated that the parties agreed the wok would be
completed and installed no later than December 26, 2013, however, Appellants failed to
timely manufacture and install the wok. (CR 2). Appellee sued Appellants for breach of
contract based upon the failure to timely manufacture and install the wok. (CR 2). There is
clearly a causal nexus between the breach of contract and Appellee’s damages.
Furthermore, in the affidavit of John Chen, Appellee reiterates the facts plead in Appellee’s Original Petition, as well as additional facts and damages associated with
Appellants breach. John Chen, one of the owners and directors of Hunan Ranch, clearly
establishes that there was an agreement for Appellees to manufacture and install a new
commercial wok at Hunan Ranch. (CR 17). The new wok was to replace the existing wok at
Hunan Ranch, and the installation was to occur no later than December 26, 2013. (CR 17-
18). Appellants did not have the new wok ready for the December 26, 2013 deadline, but
represented on at least two occasions, that the new wok would be ready on January 8, 2014.
(CR 18). John Chen further explained in his affidavit that the installation of the new wok
was to coincide with the renovations at Hunan Ranch. Id. Appellants did not show up to
install the new wok on January 8, 2014. Id. Appellee contacted Appellants following
Appellants failure to deliver and install the wok and were told the new wok would be ready
on January 11, 2014. Id. However, on January 11, 2014, Appellants did not deliver the new
wok and did not answer phone calls from Appellee. Id .
Appellee finally delivered and installed the old wok on January 16, 2014 and Appellee was able to open its restaurant for dinner on January 17, 2014. (CR 18). In their
brief, Appellants state that the old wok range was not removed because of any defects,
which is stated nowhere in the certified record. (Appellants’ brief pg. 24). Further with no
support, Appellants state that it was due to third-party contractors of Appellees that the old
wok was not installed. Id. Appellants, with through not support in the certified record,
though they misleadingly cite to the certified record, attempt to place the blame one a third
party. However, through the affidavit of John Chen, which is actually part of the certified
record, Appellee very clearly stated that the delay in opening the restaurant was caused by
Appellants failure to deliver and install the new wok. (CR 18). Specifically, John Chen
testifies, “Due to Defendants’ failure to deliver and install the new wok, there was a delay of
8.5 (January 9, 2014 through dinner on January 17, 2014) between the expected date of
installation of the new wok and the re-installation of the old wok.” (CR 18-19). There is
clearly no doubt as to the cause of the breach and damages. Appellee further properly pleads
that due to the delay in the delivery of the wok, Appellee suffered damages in the amount of
$37,993.81. (CR 19).
Appellants correctly state that a plaintiff must prove two causal nexuses: (1) between the defendant’s conduct and the event sued upon and (2) between the event sued upon and
the plaintiff’s injury. Morgan , 675 S.W. 2d at 731. As discussed above, Appellee has
provided proof of both of these nexuses. The facts plead in both the affidavit and Original
Petition are more than enough to establish both the causal nexuses. The facts plead by
Appellee have been properly plead and therefore admitted.
Reply to Issue 5: Hunan Ranch proved its damages and therefore is
entitled to the awarded attorney’s fees. Hunan Ranch has proved there was a breach of contract by Appellants and damages stemming from same. Therefore, as plead in Appellee’s Original Petition and granted by the
court, Appellee’s are entitled to attorney’s fees. (CR 1-3, 9-11). Under T EX . C IV . P RAC . &
R EM . C ODE A NN . § 38.001, a person may recover reasonable attorney’s fees from an
individual or corporation, in addition to the amount of a valid claim and costs, if the claim is
for: (8) an oral or written contract. Appellee has alleged and proved a breach of contract in
its Original Petition, as well as through the affidavit of John Chen. (CR 1-3 and 17-19). In a
no-answer default judgment, all facts properly plead are deemed admitted. Morgan , 675
S.W.2d at 732; Whitaker , 218 S.W.3d at 220. Therefore, Appellee has plead and proved its
claim for breach of contract.
Additionally, Appellee has proven a causal nexus between the breach of contract and the Appellee’s injuries. Specifically, Appellee has stated in both its Original Petition and
affidavit of John Chen, that there was an agreement that was breached. (CR 1-3 and 17-19).
Additionally, Appellee established that due to Appellants’ breach and failure to timely
deliver the new wok, Appellee suffered damages. Appellee provided evidence to support its
claim for unliquidated damages. An affidavit does satisfy the requirements of T EX . R. C IV . P.
243.
Since Appellee was able to prove a breach of contract and damages associated with the breach of contract, Appellee is entitled to the awarded attorney’s fees.
PRAYER
Because Hunan Ranch Corporation properly filed its Original Petition and provided sufficient evidence of liability and damages, which is supported by the certified record.
Appellants failed to meet their burden for a restricted appeal by failing to prove there was
error on the face of the record. Accordingly, Appellee asks this Court to affirm the trial
court’s judgment. Furthermore, Appellee asks that attorney’s fees be awarded for the appeal
in the amount of $15,000.00 as awarded in the Final Judgment.
Respectfully Submitted,
HAJJAR PETERS, LLP 3144 Bee Caves Road Austin, Texas 78746
Telephone: (512) 637-4956 Facsimile: (512) 637-4958 *19 By: /s/Teresa C. Baker________________ Doran D. Peters State Bar No. 24027615 Teresa C. Baker State Bar No. 24053131 Service@legalstrategy.com ATTORNEYS FOR APPELLEE CERTIFICATE OF COMPLIANCE I certify that the foregoing documents contains approximately 4,081 words, in compliance with T EX . R. A PP . P. 9.4(i).
/s/Teresa C. Baker_________________ Teresa C. Baker CERTIFICATE OF SERVICE
I certify by my signature that a true and correct copy of this pleading has been served via the method indicated below, pursuant to the Texas Rules of Civil Procedure 21 and 21a,
to the person(s) noted below on this the 30th day of March, 2015:
Janice L. Ta
Michelle Arishita
Frank C. Brame
VINSON & ELKINS LLP
2801 Via Fortuna, Suite 100
Austin, Texas 78746
jta@velaw.com
marishita@velaw.com
fbrame@velaw.com
/s/Teresa C. Baker_________________ Teresa C. Baker
[1] The terms “parties” is used to collectively refer to Hunan Ranch Corporation, Ha Duong Nhu and D&H Restaurant Equipment.