(a) In a suit brought under Section 315.092, an affidavit must be attached to the plaintiff's petition stating:
- (1) that the matters alleged in the petition are true, except for matters alleged on information and belief; and
- (2) that the suit is brought in good faith and not to injure or delay the municipality, the contractor, or an owner of abutting property.
- (b) If the plaintiff does not attach the affidavit required by this section, the court shall dismiss the suit on a defendant's motion and the plaintiff is barred to the same extent as if suit had not been brought.
Acts 1995, 74th Leg., ch. 165, Sec. 1, eff. Sept. 1, 1995.