(a)

1. (1) For contracts entered into on or after January 1, 2026, a direct contractor making or taking a contract in the state for the erection, construction, alteration, or repair of a building, structure, or other private work, shall assume, and is liable for, any indebtedness for the performance of labor, including that described in subdivision (b) of Section 8024 of the Civil Code, incurred by a subcontractor at any tier acting under, by, or for the direct contractor included in the subject of the contract between the direct contractor and the owner. The direct contractor’s liability under this section shall be limited to payments for labor required by the subcontractor’s agreement with the laborer or the subcontractor’s collective bargaining agreement with the labor organization representing the laborer.
2. (2) Subject to paragraph (3), the direct contractor’s liability under this section shall extend to any indebtedness for labor described in paragraph (1), penalties or liquidated damages, and interest owed by the subcontractor on account of the performance of the labor.

3. (3) The direct contractor’s liability under this section shall extend to penalties and liquidated damages only as follows:

   1. (A) The contractor shall monitor the payment by the subcontractor of wage, fringe or other benefit payment or contribution to the employees or the labor trust fund, by periodic review of the subcontractor’s payroll records which, at a minimum, contain the information set forth in subdivision (a) of Section 226, and which are payroll records as contemplated by Section 1174.
   2. (B) Upon becoming aware of the failure of the subcontractor to pay the wage, fringe or other benefit payment or contribution to the employees or the labor trust fund, the contractor shall diligently take corrective action to halt or rectify the failure, including, but not limited to, retaining sufficient funds due the subcontractor for work performed on the private construction project.
   3. (C) Prior to making final payment to the subcontractor for work performed on the private construction project, the contractor shall obtain an affidavit signed under penalty of perjury from the subcontractor that the subcontractor has paid the wage, fringe or other benefit payment or contribution due to the employees or the labor trust fund for all work performed on the private construction project.

   If a worker employed by a subcontractor on a private construction project is not paid the wage, fringe or other benefit payment or contribution owed by the subcontractor on account of the worker’s performance of labor on that project, the direct contractor of the project is not liable for any associated penalties or liquidated damages under paragraph (2) unless the direct contractor had knowledge of the subcontractor’s failure to pay the specified wage, fringe or other benefit payment or contribution, or the direct contractor fails to comply with all of the following requirements:

4. (4) The Division of Labor Standards Enforcement shall notify the contractor and subcontractor on a private works project within 15 days of the receipt by the Division of Labor Standards Enforcement of a complaint of the failure of a subcontractor on that private works project to pay the specified wage, fringe, or other benefit due to workers.
5. (5) A direct contractor or any other person shall not evade, or commit any act that negates, the requirements of this section. This section does not prohibit a direct contractor or subcontractor at any tier from establishing by contract or enforcing any otherwise lawful remedies against a subcontractor it hires for liability created by any indebtedness for labor described in this subdivision by that subcontractor or by a subcontractor at any tier working under that subcontractor, including liability for associated penalties and liquidated damages.

(b)

1. (1)

   1. (A) The Labor Commissioner may enforce against a direct contractor the liability created by subdivision (a) pursuant to Section 98 or 1197.1, or through a civil action.
   2. (B) The Labor Commissioner shall notify the direct contractor and subcontractor at any tier on a private works project at least 30 days prior to a hearing held on an administrative complaint pursuant to Section 98, prior to issuance of a citation pursuant to Section 1197.1, or prior to filing a civil action, for the failure of a subcontractor on that private works project to pay the specified wage, fringe, or other benefit due to workers. The notice need only describe the general nature of the claim, the project name or address, and the name of the employer. The notice shall not preclude subsequent amendments of an action to encompass additional contractors or wage claimants employed by the subcontractor.
2. (2) A person or entity described in subdivision (c) of Section 8024 of the Civil Code may bring a civil action against a direct contractor to enforce the liability for any unpaid wage, fringe or other benefit payment or contribution, penalties or liquidated damages, and interest owed by the subcontractor on account of the performance of the labor pursuant to subdivision (a). The court shall award a prevailing plaintiff in such an action its reasonable attorney’s fees and costs, including expert witness fees.

3. (3)

   1. (A) A joint labor-management cooperation committee established pursuant to the federal Labor Management Cooperation Act of 1978 (29 U.S.C. Sec. 175a) may bring an action in any court of competent jurisdiction against a direct contractor or subcontractor at any tier to enforce liability for any unpaid wage, fringe or other benefit payment or contribution, penalties or liquidated damages, and interest owed by the subcontractor on account of the performance of the labor on a private work pursuant to subdivision (a). Prior to commencement of an action against a direct contractor to enforce the liability created by subdivision (a), the committee shall provide the direct contractor and subcontractor that employed the wage claimant with at least 30 days’ notice by first-class mail. The notice need only describe the general nature of the claim, the project name, and the name of the employer, and shall not limit the liability of the direct contractor or preclude subsequent amendments of an action to encompass additional wage claimants employed by the subcontractor.
   2. (B) A joint labor-management cooperation committee established pursuant to the federal Labor Management Cooperation Act of 1978 (29 U.S.C. Sec. 175a) may bring an action in any court of competent jurisdiction against a direct contractor to enforce liability for any unpaid wage, fringe or other benefit payment or contribution, penalties or liquidated damages, and interest owed by the direct contractor on account of the performance of the labor on private work.
   3. (C) In a claim brought pursuant to subparagraph (A) or (B), the court shall award a prevailing plaintiff its reasonable attorney’s fees and costs, including expert witness fees.
4. (4) No other party may bring an action against a direct contractor to enforce the liability created by subdivision (a).
5. (5) Any liquidated damages awarded by the Labor Commissioner or the court shall be payable to the aggrieved employee.
6. (6) An action pursuant to this section shall not be based on the employer’s misclassification of the craft of a worker.
7. (7) The remedies created by this section are cumulative of any other available remedies.

8. (8)

   1. (A) A direct contractor that makes contribution payments pursuant to subparagraph (B) shall not be held liable pursuant to paragraphs (1) to (3), inclusive, with respect to fringe or other benefit contributions.

   2. (B) If a direct contractor has been provided documentation that the subcontractor has been notified by the trust, plan, fund, or program that the subcontractor has failed to make timely required contribution payments for a private construction project, the direct contractor may make the contribution payments for performance of labor for that project in compliance with all of the following:

      1. (i) The direct contractor makes a payment using a joint check made payable to the subcontractor and the trust, plan, fund, or program for any fringe or other benefit payment or contribution.
      2. (ii) The subcontractor provides the name, type, number, and address of the trust, plan, fund, or program to the direct contractor.
      3. (iii) The direct contractor notifies the trust, plan, fund, or program that it has paid the subcontractor with a joint check.

(d) An action brought pursuant to this section shall be filed within one year of the earliest of the following:

1. (1) Recordation of the notice of completion of the direct contract, pursuant to Section 8182 of the Civil Code.
2. (2) Recordation of a notice of cessation of the work covered by the direct contract, pursuant to Section 8188 of the Civil Code.
3. (3) Actual completion of the work covered by the direct contract.

(f)

1. (1) Upon request by a direct contractor to a subcontractor, the subcontractor and any lower tier subcontractors under contract to the subcontractor shall provide payroll records, which, at a minimum, contain the information set forth in subdivision (a) of Section 226, and which are payroll records as contemplated by Section 1174, of its employees who are providing labor on a private work, which payroll records shall be marked or obliterated only to prevent disclosure of an individual’s full social security number, but shall provide the last four digits of the social security number. The payroll records must contain information sufficient to apprise the requesting party of the subcontractor’s payment status in making fringe or other benefit payments or contributions to a third party on the employee’s behalf.
2. (2) Upon request of a direct contractor to a subcontractor, the subcontractor and any lower tier subcontractors under contract to the subcontractor shall provide the direct contractor award information that includes the project name, name and address of the subcontractor, the contractor with whom the subcontractor is under contract, anticipated start date, duration, and estimated journeymen and apprentice hours, and contact information for its subcontractors on the project.
3. (3) A subcontractor’s failure to comply with this subdivision shall not relieve a direct contractor from any of the obligations contained in this section.

(g) For purposes of this section, the following definitions apply:

1. (1) “Direct contractor” means a contractor that has a direct contractual relationship with an owner or any other person or entity engaging contractors or subcontractors for the erection, construction, alteration, or repair of a building, structure, or other private work on behalf of the owner.
2. (2) “Subcontractor” has the same meaning as provided in Section 8046 of the Civil Code.