154 Mo. App. 646 | Mo. Ct. App. | 1911
This is a suit brought by the plaintiff against D. R. Elmore and Son, and Sam Jones and M. Beckman, for $321.71. In July, 1908, the plaintiff made a contract with said Elmore and Son to build a residence for him. At the time the contract was made, a bond was executed by the contractors to the plaintiff, with the defendants, Jones and Beckman as sureties, in the sum of one thousand dollars, for the completion of the building, according to- the plans and specifications. The contractors failed to complete the building according to the contract or the plans and specifications, and also failed to pay bills for material, so that the plaintiff, in addition to the contract price, was compelled to pay the above sum.
This suit was instituted against the contractors and the sureties. The cause was tried before the court without a jury, resulting in a judgment in favor of the plaintiff and against the contractors for $259.45, but in favor of the sureties. The plaintiff appealed from that judgment to this court, and the only question for decision here is, whether the trial court was right in excusing the sureties on the bond.
The written contract for the completion of the building, entered into between the plaintiff and the contractors, expressly authorized changes in the work and in the plans and specifications. The bond, however, was not conditioned for the performance of the
The contract provided the work should be done within a specified time and a penalty of a certain amount per day was added for the failure so to do. The plans and specifications made no provision for any. changes, and contained no clause requiring the work to be done within a specified time, or a penalty for failure to do so. The sureties claim that without their consent the plaintiff and the contractors made alterations and changes in the building, and on account thereof, they were released.
The only testimony relating to the changes was given by the plaintiff. He testified that the doors, were made six inches larger than called for in the plans, and he paid the contractors therefor $2.50; that another change was made in a door, and he paid therefor fifty cents; that a change was made in the way of attaching rafters, resulting in extra plastering, almounting to $17.75; that a change was made in the balcony by leaving out one window and moving one, and that he paid the contractors extra therefor the sum of $18; that shingles were substituted for ridge poles at the extra expense of $2.25.' He also testified to a number of other changes made under an agreement between himself and the contractors without the consent of the sureties, but that said changes in no wise increased the cost of the building.-
Had the bond been conditioned that the contractors should construct the building according to the contract, then the changes made under an agreement between the plaintiff and the contractors would not release the sureties. The contract expressly provided that changes might be made, and where the contract so reads and the bond is conditioned for its faithful performance, then the
The bond in this case does not provide for the completion of the contract by the contractors in all its details. It simply provides for the completion of the contract “by completing the building as described by the plans and specifications.”
It must be accepted as the settled law of this state, that there is no implied obligation on the part óf a surety that he has undertaken more or other than that expressed in his contract, and it is only to the extent and in the manner and under the circumstances pointed out in his bond, is he bound. [Bauer v. Cabanne, 105 Mo. 110, 16 S. W. 521; Nofsinger v. Hartnett, 84 Mo. 549; Reissaus v. Whites, supra; Beers v. Wolf, 116 Mo. 179, 22 S. W. 620; School Dist. v. Green, 134 Mo. App. 421, 114 S. W. 578.]
It is also well settled that any substantial change made in the contract by the principal and the contractor without the consent of the surety, will release the latter, regardless whether the alterations were injurious or beneficial to the surety. [Higgins v. Deering Harvester Co., 181 Mo. 300, 79 S. W. 959; Burnes’ Estate v. Fidelity & Dep. Co., 96 Mo. App. 467, 70 S. W. 518.]
In this case the sureties’ undertaking, when strictly construed, only required the performance of the contract to the extent of completing the building according to the plans and specifications. Their liability therefore, is not to be measured by obligations requiring the completion of the building according .to a contract in which are provisions for changes and alterations. [School Dist. v. Greene, 134 Mo. App. 421, 114 S. W. 578.]
The second count of plaintiff’s petition is based upon the fact that the contractors did not complete the building within the time specified in the contract. The contract provided liquidated damages of three dollars per day for each day the work remained incom
As we have stated, the condition of the bond was not for the full performance of the contract in every particular, and therefore, the sureties were not liable for the failure to perform that part of the contract. This part of the opinion is mitten solely for the purpose of illustrating the other issue in the case.
In as much as the bond is not conditioned for the performance of all the terms of the contract, the liability of the sureties must be limited to the parts of the contract mentioned and described in the bond, to-wit: By completing the building as described by the plans and specifications.
The contention of appellant is, that the changes were so immaterial that they should be ignored. There is much merit in this contention. If Ave were free from controlling decisions in this state, we might adopt appellant’s view. But in Beers v. Wolf, 116 Mo. 179, 22 S. W. 620, the contract price for the work was over $31,000. The real expense and cost of changes amounted to a little over $221. The contention was that they were so immaterial that they should be ignored. The Supreme Court, speaking through Black, J., said: “Can it be said these changes, taken as a whole, were so small that the law will take no notice of them? We think not. No case to which we are cited will justify any such conclusion. To a suit to recover the expense brought about by these alterations, it would be no answer to say that they were immaterial. These changes destroyed the identity of the contract, and that is suffi
In addition to the changes heretofore enumerated and which were made at an increased cost, there were numerous changes made by agreement between the plaintiff and the contractors. Some of them in no manner effected the actual cost of the building, and a number of them decreased the cost thereof. But when all the alterations are taken together, they substantially changed the contract, and under the rule in this state, that the surety has the right to stand on the very letter of his contract, and that any material change in the same, without his consent, releases him, we are of the opinion that the trial court did not err in holding the sureties were not liable in this case, and the judgment will be affirmed.