104 N.E. 922 | NY | 1914
The Supreme Court at Special Term granted to the relator a writ of peremptory mandamus commanding the appellant, as chief engineer of the public service commission, to make a written determination upon the claim of the relator for compensation for extra work performed under a contract for the construction of a part of the present subway system in Greater New York. Such an application as this is governed by the well-settled and familiar rule that the relator must show a clear legal right to the writ and that it has no other legal remedy. This rule is too firmly established to justify the citation of authority.
The provisions of the so-called Rapid Transit Act (L. 1891, chap. 4, as amended) brought into existence the board of rapid transit railway commissioners. In 1902 this board, for and on behalf of the city of New York, entered into a contract with the relator for the construction, equipment and operation of the Brooklyn-Manhattan Rapid Transit railroad, which extends from a point near the general post office building in Manhattan to the Flatbush avenue station of the Long Island railroad in Brooklyn. This was done pursuant to powers specifically granted to the commission by the statute.
In this proceeding we are concerned only with a sub-contract *446 for construction, known as sub-section 2-A, which the relator sublet to one Onderdonk, who in turn assigned it to the New York Tunnel Company. The stretch of road to be built under that sub-contract extended from Manhattan across the East river to Joralemon street and thence to Fulton street in Brooklyn.
Pursuant to the command of the statute the commission appointed a chief engineer, the appellant herein, and when the contract with the relator was made that instrument defined with great particularity the powers and duties of the chief engineer respecting the preparation of plans and the conduct of the work. By the terms of the contract the commission reserved the broadest power to amplify the plans, to add explanatory specifications, and to furnish additional specifications and drawings within the limits of the general purview of the work. It was expressly stipulated that this might be done during the progress of the work, and that if any additional burden should be cast upon the contractor it was to receive reasonable extra compensation. In these circumstances it was necessary, of course, to clothe the chief engineer with such broad powers as would enable him to carry out the directions of the commission. These powers are set forth in the contract with an amplitude of detail that need not be repeated here, and we shall content ourselves with paraphrasing a few of its provisions which bear directly upon the question at issue.
The contract provides that if the engineer shall direct that additional specifications or drawings or details shall be followed by the contractor, or if any question shall arise as to the quantity, quality or character of the work or materials furnished, or as to the amount to be added to or deducted from the contract price; or if any dispute, question or doubt shall arise as to the contract or its obligation at any time prior to the complete construction and equipment of the railroad, the determination of the engineer shall be binding upon the contractor and the *447 city so far that the contractor shall, "as the case may be, proceed or refrain from proceeding and without any delay obey the requirement of the engineer."
The contract further provided that the determination of the engineer shall be in writing and that duplicate copies thereof should be filed with the city and served on the contractor. The determination of the engineer as to work done or materials supplied was to be binding and conclusive upon the city, unless the commission should appeal within ten days after the filing of such determination, and notice of filing given to the president of the commission; and it was to be binding upon the contractor unless it should appeal within ten days after receiving a duplicate copy of the determination. The contract then proceeds to set forth the explicit provisions for the appointment of arbitrators to hear and determine appeals from the engineer's determinations, and for the procedure on such appeals.
In view of these features of the contract, it is important to note another provision under which the contractor should be entitled to additional payments for additional work by reason of additional specifications, drawings, details or other requirements, "only upon the production of the certificate anddetermination of the engineer, if unappealed from," or, if appealed from, "then only upon and according to the final awardof the arbitrators."
In the effort to comply with these provisions of the contract, the relator filed claims for extra work amounting to $3,420,022.70, which are classified "A claims," amounting to $2,536,429.53, and "B claims," amounting to $833,593.17.
The appellant engineer refused to pass upon these claims on the ground that under the contract he had no right to make a determination because it would "inevitably involve the city in litigation;" and his reason seems to have been that the principal parts of these large claims for extra compensation were presented by the *448 relator, not on its own account, but as the representative of the tunnel company; and that the latter company, according to the appellant's view, had no right to make a claim for extra compensation because of the stipulations of a so-called supplemental contract between the relator and the tunnel company, under which it is contended the latter had foreclosed both itself and the relator from making any valid claims for extra work done by the tunnel company.
In respect of the appellant's contention regarding the legal effect of the so-called supplemental agreement between the relator and the tunnel company, we need only say that if it was the appellant's duty to pass upon the relator's claims, he was bound to perform it; and it would have been as fully performed by his refusal to recognize their validity in whole or in part as it would have been if he had certified to their validity. If it was his duty to act upon the claims, he could not refuse, because, in his view of the law, the relator's claim could not be sustained. That was a matter in respect of which the contract provided for a review of his decision by arbitrators, to be appointed in the method prescribed by the contract.
The writ directed to the appellant commands him "to make, file and deliver" his determination of the claims presented by the relator. It does not direct how that determination shall be made, but simply compels action one way or the other. In that respect it conforms to well-established rules of law which were clearly stated by Judge VANN in People ex rel. Harris v. Commissionersof Land Office (
In the case at bar the writ commands the appellant to perform a duty enjoined upon him by the express terms of a contract which has the force of a public statute; and being a quasi public official that is a duty, the performance of which may be enforced by mandamus unless the relator has another remedy at law. The circumstances disclosed by this record clearly indicate that the relator has no other remedy.
Counsel for the appellant contends that the refusal of the appellant to pass upon the relator's claims gives the latter a cause of action at law, and in support of his argument he cites certain cases which hold that when an architect unreasonably and in bad faith refuses a certificate, which in other circumstances would be a prerequisite to a right of action in favor of a contractor against the owner, the production of such a certificate is not necessary. (Thomas v. Fleury,
The rule established by these cases is no longer open to question, but we think it has no application to the case at bar. Here the parties to the contract have undertaken to provide by arbitration, so far as possible, for the settlement of all disputes which may arise out of claims for extra compensation. This plan was doubtless suggested by the obvious fact that the character of the work, no less than the almost unlimited power of the commission and its engineer to make changes therein, rendered it necessary to submit to experts the technical engineering and other problems *450
which would naturally enter into such controversies. The parties had the right to make such an arrangement unless it goes so far as to bring it within the condemnation of certain cases which hold that arbitration agreements are invalid if their purpose and effect is to oust the courts of jurisdiction. (Haggart v.Morgan,
The order of the Appellate Division should be affirmed, with costs.
WILLARD BARTLETT, Ch. J., HISCOCK, CHASE, COLLIN, HOGAN and MILLER, JJ., concur.
Order affirmed. *451