127 F. 55 | 5th Cir. | 1904
after stating the case as above, delivered the opinion of the court.
By the terms of the contract the garbage furnace was not to be paid for until it was “completed and tested according to the satisfaction of the committee.” - It is not alleged in the petition that the work was completed and that the test was made to the satisfaction of the committee. The'petition shows that the committee has not expressed its satisfaction with the furnace, and, on the contrary, has refused to accept it. When a person agrees to do certain work for another, to be paid for only when done to the “satisfaction” of the other or of a third party, there are unquestionably circumstances under which the contractor may enforce payment, although the promisor or third party withholds the expression of his satisfaction. Are such circumstances or facts alleged in this petition ? That is the question raised by the demurrer. To answer it, regard must be had not only to the special averments relating to the withholding by the committee of its expression of satisfaction with the work, but to the other averments showing the nature and scope of the contract.
The plaintiff agreed to build on the defendant’s land a garbage furnace, which is a permanent structure or immovable fixture. The case, therefore, differs from similar contracts as to manufactured articles or personal chattels where the parties, upon a rescission, could be placed in their former condition without loss, or with trifling loss, to the promisee. It is important to note, also, that the furnace was to be built according to plans and specifications which were made part of the contract.
Havirig in view these facts, which appear from the petition, let us .examine the special averments on which the plaintiff bases its right to recover, notwithstanding the committee withholds expression of its satisfaction:
“Said furnace has been tested, and found in all things to comply with said plans and specifications and requirements of said contract. But the committee of the common council of the defendant, without just cause or reason, and moved by caprice and prejudice, has refused to express satisfaction with such tests, although the operation of said furnace under the tests aforesaid, by reason of the compliance with the contract on the part of plaintiff in the construction of said furnace disclosed thereby, should have fully satisfied said committee and defendant, and would Have satisfied persons of ordinary care, caution, prudence, and fairness.”
The cases decided where contracts containing somewhat similar conditions have been construed have usually been conditional promises to pay upon the. satisfaction with, or approval of, the work or article by the promisor himself or a third person. In examining
The courts have had frequent occasion to construe contracts for the rendition of services, the manufacture of articles, and the construction or improvement of works, wherein it was agreed as a'condition precedent to payment that the services, articles, construction, or improvement should be satisfactory to the promisor. Such contracts are of two kinds: First, where the right of decision is completely reserved to the promisor without his being required to disclose the reasons for his determination, and all right to inquire into the grounds of his decision or to examine and overhaul his determination by the promisee or the courts is absolutely excluded. The law regards the parties as competent to contract in that manner, and, if the contract is to that effect, it is the law of the case. Second, where the promisor is held to have undertaken to act reasonably and fairly and to found his determination on grounds which are reasonable, just, and sensible. Where the construction of the contract puts it in the second class, it follows as a necessary implication that the promisor’s decision, in point of correctness and the adequacy of his grounds, is open to judicial determination.
Whether a particular contract falls within the first class., where the promisor’s decision is final, or in the second class, where it is subject to judicial investigation, depends on the special circumstances of each case. In contracts which involve the taste, feelings, or sensibility of the promisor, he may reject an article or work arbitrarily which has been mutually agreed should be made or done to his satisfaction. Pennington v. Howland, 21 R. I. 65, 41 Atl. 891, 79 Am. St. Rep. 774 (pastel portrait); Gibson v. Cranage, 39 Mich. 49, 33 Am. Rep. 351 (portrait); Zaleski v. Clark, 44 Conn. 218, 26 Am. Rep. 446 (bust); Brown v. Foster, 113 Mass. 136, 18 Am. Rep. 463 (suit of clothes).
There are also contracts subject to the same construction where questions of taste are not involved. It sometimes appears from the terms of the contract and the circumstances surrounding the parties that the promisor retained the unqualified right to reject the article or work if not satisfied with it; that his freedom of choice was not to be exposed to any contingency or subject to any review. Such contract may be injudicious and indiscreet on the part of the contractor who agrees to do work and furnish material on such a hazardous contingency, but, when such is clearly the agreement, the courts cannot afford relief against the consequences resulting from
When the terms or the nature of the contract, or the circumstances, are such as to make it doubtful whether the contractor has really agreed that the promisor shall have the absolute and unreviewable right to reject the article or the work if not satisfied with it, the courts have Usually construed such contracts as “agreements to do the tiling in such way as reasonably ought to satisfy the defendant.” In Hawkins v. Graham, 149 Mass. 284, 21 N. E. 312, 14 Am. St. Rep. 422, where a heating apparatus “satisfactory” to the promisor was to be furnished, it was held that the satisfactoriness was “to be determined by the mind of a reasonable man, and by the external measures set forth in the contract, not by the private taste or liking of the defendant.” In reaching this conclusion the court was influenced somewhat by the fact that the consideration, furnished “was of such a nature that the value will be lost to the plaintiff, either wholly or in great part,” by a different construction of the contract.
In Rawlins v. Honolulu Co., 9 Hawaiian, 262, the plaintiff agreed to work in a skillful and proper manner to the satisfaction of the defendant. Construing the contract, the court said that the defendant was bound to be satisfied if the work was done in a skillful and proper manner. The court observed that the fact that one is the sole judge does not authorize him to act whimsically or in bad faith.
In Northern Pacific Co. v. Portland (Or.) 12 Pac. 5, it was held that, where a city by its contract agrees to pay for an improvement upon its completion and the approval of it by the city, it cannot avoid its liability by delaying to approve the work when it is completed according to the contract.
• In Duplex Boiler Co. v. Garden, 101 N. Y. 387, 4 N. E. 749, 54 Am. Rep. 709, the plaintiff by contract agreed to alter certain boilers in the manner specified, the stipulated price for the work to be paid by the defendants as soon as they are satisfied that the boilers as changed are a success. It was held that a simple allegation of dissatisfaction on the part of the defendants, without a good reason, was no defense. The court said “that which the law will say a contracting party ought in reason to be satisfied with, that the law will say he is satisfied with.”
In Doll v. Noble, 116 N. Y. 230, 22 N. E. 406, 5 L. R. A. 554, 15 Am. St. Rep. 398, the.contract sued on was for staining and rubbing Woodwork in two houses owned by the defendant. The work was to be done in the best workmanlike manner and to the entire satisfaction of the owner. The court held that, if it was done in the best workmanlike manner, the owner could not defeat recovery of the price agreed to be paid by arbitrarily and unreasonably declaring that it was not done to his satisfaction.
In Folliard v. Wallace, 2 Johns. 395, Kent, C. J., construed a contract whereby the defendant was to pay “three months after being well satisfied,” etc., as to title to land. He said: “The law in this case will determine for the defendant when he ought to be satisfied.”
Kent, in Folliard v. Wallace, supra, noted the fact that this view is sustained also by writers on the civil law: “There is a real obligation contracted if I promise to give you something in case I judge it reasonable; for it is not left to my choice to give it to you or not, since I am obliged to do so if it is reasonable.” 1 Pothier on Obligations (2 Am. Ed.) 22, marg. p. 48.
The defendant contends that the committee which was to be satisfied with the work and the test was, in effect, a third person. It is claimed that the case is similar to Martinsburg, etc., Railroad v. March, 114 U. S. 549, 5 Sup. Ct. 1035, 29 L. Ed. 255. There March contracted to do grading and masonry on a section of the company’s railroad, and “to prevent disputes” it was mutually agreed that the tompany’s engineer should determine the amount and quantity of work, and that whenever the contract should be completely performed on the part of the contractor, and the engineer should certify the same in writing, with his estimate, the company shall within 30 days after the receipt of the certificate pay to the contractor the sum due. The court held that in the absence of “fraud, or such gross mistake as would necessarily imply bad faith, or a failure to exercise an honest judgment, the action of the engineer was conclusive upon the parties.” It was held on the facts alleged that the decision of the engineer was binding; but it is clearly implied by the language of the opinion that the court would go behind the decision of the engineer in either one of the three named events. Sweeney v. United States, 109 U. S. 618, 3 Sup. Ct. 344, 27 L. Ed. 1053; Chicago, etc., Railroad v. Price, 138 U. S. 185, 11 Sup. Ct. 290, 34 L Ed. 917; United States v. Gleason, 175 U. S. 588, 20 Sup. Ct. 228, 44 L- Ed. 284; and Boettler v. Tendick, 73 Tex. 488, 11 S. W. 497, 5 L. R. A. 270 — are to the same effect.
These cases show that where the contract names a third party to estimate and approve the work his decision is conclusive, except that the courts may'go behind it for (1) fraud, (2) bad faith, (3) to use the words found in the last case cited, “or any dishonest disregard of the rights of the contracting parties.”
In the petition before us it is alleged that the furnace was built in conformity with the contract; that it was tested and found to meet its requirements; and that the committee, “without just cause or reason, and moved by caprice and prejudice, has refused to express satisfaction with such tests.” Taken in connection with the facts stated in the petition, this is equivalent to an averment that the committee has failed to exercise an honest judgment in discharging the duty imposed upon it. When the facts alleged show that the committee has acted unjustly, and it is averred that they so acted from prejudice and caprice, it is equal to an averment that it acted in bad faith. If the committee be considered a third person, selected tp approve the work as a condition precedent to payment, an unreasonable refusal to approve it, caused by prejudice and caprice, will
We hold that where a contractor agrees to furnish the material and to erect on the land of a municipal corporation a garbage furnace according to plans and specifications, which are-part of the contract, and warrants its capacity to consume a named quantity of garbage without emitting offensive odors, to be paid for when completed and tested according to the satisfaction of the committee of the town’s council, and the contractor performs the contract according to plans and specifications, and, the test being made, the furnace is shown to have the capacity warranted, and in all things to comply with the contract, the committee cannot' defeat the contractor’s right of recovery by capriciously and unreasonably refusing to express its satisfaction with the work. A due regard to justice seems to require such construction of the contract before us.
It follows that a declaration in a suit for the contract price which shows these facts, and alleges that the committee “without just cause or reason, and moved by caprice and prejudice, has refused to express satisfaction with such tests,” although the work and tests “should have fully satisfied the committee and the defendant, and would have satisfied persons of ordinary care, caution, prudence, and fairness,” is not subject to demurrer, as showing no cause of action, nor to special demurrer, because it is not alleged that the furnace was tested to the satisfaction of the committee.
The court, we think, erred in sustaining the demurrers to the petition.
The judgment must be reversed, and the cause remanded, with instructions to overrule the demurrers to the petition.