175 Wis. 387 | Wis. | 1921
The first cause of action sets out numerous items for which recovery is sought, and it is elementary that if any of them are well pleaded a general demurrer thereto should not be sustained'
The allegations in the complaint in reference to the duty of the city to cause the removal of the street-car tracks and gas mains are to the effect that both the street car company and the gas company operated under franchises from the city arid that therefore, under the terms of the contract and by virtue of the franchises, it became the duty of the city to cause the removal of the street-car tracks and gas mains from the old bridge, which it is conceded it was the duty of the plaintiff to remove.. It is alleged tbit finally, after a delay of eleven days, the street-car track was caused by the city to be removed, and after a delay of four days more the gas mains were caused to be removed. It is also alleged thát the plaintiff, pursuant to notice by the city to commence work April 1, 1915, was prepared to do so, that he had procured material, hired men, and was in readiness to proceed with the work, but was delayed because of the failure of the city to seasonably require the removal of the street-car tracks and gas mains, to his damage in all in the sum of $1,500.
Conceding for the purpose of the case that it was the duty
Paragraph 14 of the contract provides, among other, things, that “no charge made by the contractor for any delays or hindrances from any cause during the progress of the work or any portion thereof, embraced in the contract, will be allowed. If the delay be caused by any act or neglect of the city, then he will be entitled to an extension of the time allowed for the completion of the work, sufficient to compensate for the delay, to be determined by the engineer, provided the contractor shall give the engineer immediate notice of the cause.”
It is claimed by plaintiff that this provision of the contract does not relate to the delay charged because it was not a delay during the progress of the work but a delay before the work began. We cannot concur in such a construction. The provision was no doubt intended to cover all delays under the contract of employment — all delays which grew out of the relations created by the contract between the parties. A delay at the inception of the work must be deemed a delay during the progress thereof, for, according to plaintiff’s allegations, activities under the contract had already been begun — materials procured, men hired, and plaintiff in readiness to begin the removal of the old bridge. Under the provisions of the contract an extension of time was all plaintiff was entitled to for the delay, and that only upon giving the required notice of the cause. So we conclude the demurrer was properly sustained as to this claim for damages.
The claim for extras we deem was properly held demur-rable under the pleadings and the terms of the contract, which provided with reference thereto that “no extra work will be paid for or allowed unless the same was done upon the written order of the engineer. . . . All claims for. extra work must be made to the engineer in writing before the
Plaintiff relies largely upon the case of First Sav. & T. Co. v. Milwaukee Co. 158 Wis. 207, 148 N. W. 22, 1093, to sustain his contention that the provision in the contract that extras should be paid for only when ordered in writing by the engineer might be waived. There are several differences between this case and the one cited. There the committee in charge of the work on behalf of the county were delegated plenary powers to act in the matter, and there was. no provision for written claim for extras to be made before the payment of the next estimate. Here the engineer in charge had only the usual powers of a superintending engineer in such cases, and if it be conceded that he might waive written orders for extras it is clear he had no power to waive seasonable written claims therefor. The city council must pass upon such claims and it was entitled to the written notice provided for by the contract. Failing to give such notice the contractor must, under the terms of his contract, be “considered as having abandoned his claim.”
We come now to a class of items of damages which it is alleged were suffered by plaintiff by reason of the bad faith, fraud, or inexcusable ignorance of the engineer employed by the city. Of this class is the item of $1,200 for delays caused by the engineer set out in paragraph IV of the complaint; the item of $2,700 for damages alleged to have been caused by orders to continue to drive piles; the item of $780 alleged to have been caused by the mistake of the engineer in setting grade stakes for the south abutment of the bridge; the item of $1,689 for change in concrete arches caused by
While the contract provides in effect that the contractor shall be subject to the orders of the engineer and to the construction he gives to the plans and specifications, that does not mean he has no recourse where bad faith or inexcusable ignorance is shown by-the engineer resulting in damage to the contractor. First Sav. & T. Co. v. Milwaukee Co. 158 Wis. 207, 148 N. W. 22, 1093. Such provisions in contracts like the one in question imply that the engineer shall act in good faith and that he. is possessed of a reasonable degree of skill and care and will in good faith exercise the same in giving orders and in performing his part of the contract. Where bad faith or inexcusable ignorance on his part is shown to have resulted in damages to the contractor, who in good faith relied upon the directions of the engineer or upon the correctness of the work performed by him, then the contractor may recover the damage proximately sustained by him by reason of such bad faith or. inexcusable ignorance. First Sav. & T. Co. v. Milwaukee Co. 158 Wis. 207, 148 N. W. 22, 1093. It is therefore held that the trial court erred in sustaining the demurrer to these alleged items of damage set out in the first cause of action.
The demurrer to the second cause of action was properly sustained, first because it does not state a cause of action, separately, as required by the statute (sec. 2647, Stats. 1919), and second, if recourse is had to the first cause of action by virtue of the expressions “as above set forth,” then it appears that no proper bond upon appeal was given, for the complaint alleges an appeal to the circuit court for Eau Claire county was taken from the disallowance of plaintiff’s claim by the city council of Eau Claire and that a bond was executed conditioned “for the faithful prosecution
By the Court. — Order affirmed in part and reversed in part, as indicated.in the opinion, and cause remanded for further proceedings according to law, with costs in this court in favor of appellant.