155 N.C. App. 320 | N.C. Ct. App. | 2002
In response to a federal court mandate to promptly relieve prison facility overcrowding in North Carolina, the General Assembly enacted legislation in 1987 that transferred the responsibility and authority to design and construct prisons from the Office of State Construction (OSC) to the Office of State Budget and Management (OSBM) and exempted prison construction from various statutory requirements to help expedite prison construction. OSBM began discussions in 1987 with N.C. Monroe Construction Company (plaintiff) about building prisons for the State.
The General Assembly enacted the State Prison and Youth Facilities Bond Act, ch. 935, 1989 N.C. Sess. Laws 294 (Bond Act) on 16 July 1990. The Bond Act authorized the issuance of $200 million in state bonds, pending voter approval in November 1990. The Bond Act did not explicitly authorize State agencies to enter into contracts for the expenditure of bond proceeds, but reserved to the General Assembly the power to provide such authorization at a later date.
Plaintiff and the State entered into a management agreement on 1 August 1990 (August 1990 Agreement). C.C. Cameron, head of OSBM and Executive Assistant to the Governor for Budget and Management, negotiated and executed the August 1990 Agreement for the State. The August 1990 Agreement established plaintiff as program manager “for services in connection with the construction of those facilities described in Section 6 of . . . the State Prison and Youth Services Facilities Bond Act . . . .” Section 6 of the Bond Act provided that
[t]he proceeds of bonds and notes shall be allocated and expended for the purposes of paying the cost of prison and youth services facilities as provided in this act, the particular projects*323 within such purposes and the projected allocations therefor to be determined by legislative action of the General Assembly at the 1991 session or any subsequent session.
§ 6, ch. 935, 1989 N.C. Sess. Laws 294, 298. North Carolina voters approved the Bond Act on 6 November 1990. C.C. Cameron left state government service the following month and was replaced by Marvin Dorman (Dorman), formerly second in command at OSBM as the Deputy State Budget Officer.
The General Assembly ratified the Appropriations and Budget Revenue Act of 1991, ch. 689, 1991 N.C. Sess. Laws 1894 (Revenue Act), on 13 July 1991. The Revenue Act provided for the appropriation of $112.5 million in bonds for
financing the cost of. . . State prison facilities and youth services facilities, including, without limitation, the cost of constructing capital facilities, renovating or reconstructing existing facilities, acquiring equipment related thereto, purchasing land, paying costs of issuance bonds and notes and paying contractual services necessary for the partial implementation of the purposes of the bond act.
§ 239(a), ch. 689, 1991 N.C. Sess. Laws 1894, 2125. Section 239 of the Revenue Act allocated $103.4 million of the $112.5 million towards the construction of prison projects in the State and the remainder to construction projects in the Division of Youth Services. Id. at 2125-26. Section 239 left the remaining $87.5 million of the overall $200 million to be used as determined by subsequent legislative action during that same session or any later session of the General Assembly. Id. Section 239(f) granted OSBM the ability to contract for prison facilities, stating that
[w]ith respect to facilities authorized for the Department of Correction, the Office of State Budget and Management may contract for and supervise all aspects of administration, technical assistance, design, construction or demolition of prison facilities in order to implement the providing of prison facilities under the provisions of this act.
Id. at 2127.
At the request of Dorman, plaintiff and the State executed a second contract on 18 September 1991 (September 1991 Agreement), covering the same general services as the August 1990 Agreement,
for services in connection with the construction of those facilities described in Section 6 of . . . [the] Bond Act (200 Million Bond Issue), as enacted during the 1989 Session (May 1990 Session) of the North Carolina General Assembly . . ., a copy which is attached hereto.
However, the September 1991 Agreement includes a provision immediately after the above cited language that specifies the contract includes the entire $200 million under the Bond Act and gives the rationale for including the entire amount. The provision includes facilities
for which appropriations have been made for the Department of Corrections pursuant to Section 239(c) in House Bill 83 as enacted in the 1991 Session of the North Carolina General Assembly, as well as the facilities for which appropriations shall be made for the balance of the $87,500,000 authorized as part of the 200 Million Bond Issue.
The facilities for which appropriations have not been made are being contracted for because a) a portion of the appropriations which are to be subsequently made will be necessary to complete the facilities authorized by the current appropriation, b) planning for the entire 200 Million Bond Issue will substantially decrease delays which would otherwise occur in construction of facilities for which appropriations are to be made subsequently, and c) savings will be realized by the State of North Carolina as a result of the economy of scale for the total 200 Million Bond Issue.
(emphasis added).
A second key addition in the September 1991 Agreement was to section 6.1, which originally established the reimbursement rate for the initial $103.4 million portion of the construction project. A provision was added governing the reimbursement rate for the remaining portions of the $200 million when appropriated by the General Assembly.
At the request of the General Assembly, Dorman presented a list of prison projects to be constructed from the remaining $87.5 million
Almost a year later, the General Assembly ratified the Act of July 24, 1993, ch. 550, 1993 N.C. Sess. Laws 2906 (1993 Appropriations Act), which replaced OSBM with OSC as the agency authorized to contract for and supervise construction of prison facilities. The 1993 Appropriations Act also appropriated the remaining $87.5 million from the Bond Act and repealed sections 1 through 4 of the 1992 Appropriations Act. The General Assembly eliminated the prohibitions on entering into contracts from the portion of section 2 of the 1993 Appropriations Act, analogous to the portion of repealed section 2 of the 1992 Appropriations Act.
Plaintiff was informed its services would no longer be needed in conjunction with the construction of facilities under the Bond Act. Plaintiff was paid for all work it had performed under the $103.4 million portion of the project. Plaintiff submitted claims for payment under the $87.5 million portion of the Bond Act to OSBM on 14 May 1997, and to OSC on 1 July 1997, both of which were denied.
Plaintiff filed a complaint on 22 May 1998 seeking damages for breach of contract by the State. The State filed an answer and counterclaim on 2 September 1998. The State filed a motion for summary judgment dated 31 May 2000. Plaintiff filed an affidavit of its president, Carl Monroe, dated 4 January 2001. The State moved to strike portions of the affidavit on 10 January 2001. The trial court entered an order on 2 August 2001 denying the State’s motion to strike and granting the State’s motion for summary judgment. Plaintiff filed a motion
We must first determine whether the amended order of the trial court is immediately appealable. The order of the trial court granting the State’s motion for summáry judgment did not dispose of all the claims in this case, in particular counterclaims and third-party claims, which makes it an interlocutory order. Veazey v. Durham, 231 N.C. 357, 362, 57 S.E.2d 377, 381 (1950). N.C. Gen. Stat. § 1A-1, Rule 54(b) (2001) states that in an action involving multiple claims or parties, if the trial court enters a final judgment as to a claim or a party and certifies there is no just reason for delay, the judgment is immediately appealable, requiring appellate review. DKH Corp. v. Rankin-Patterson Oil Co., 348 N.C. 583, 585, 500 S.E.2d 666, 668 (1998). The trial court may render its judgment immediately appealable by a Rule 54(b) certification only if the judgment is final. Sharpe v. Worland, 351 N.C. 159, 162, 522 S.E.2d 577, 579 (1999). In the case before us, the trial court in its amended judgment correctly made a finding of fact and conclusion of law that its judgment was a final judgment as to plaintiffs claims against the State and certified there was no just reason for delay, thus requiring review on appeal by this Court.
Plaintiff argues that the trial court erred in granting summary judgment to the State because there is a genuine issue of material fact as to whether the State breached or wrongfully terminated valid and enforceable agreements for plaintiff to serve as program manager for the construction of prisons in North Carolina. The State responds that the trial court correctly granted its motion for summary judgment since the legislative enactments in the record show that OSBM had no authority to enter into a contract with plaintiff with respect to the $87.5 million portion of the bond program. The State therefore argues that with no authority to enter into a valid contract, “the State is immune from suit in relation to the $87.5 million portion of the bond program.”
Summary judgment should be granted only when no genuine issue of material fact is presented. Gaskill v. Jennette Enters., Inc., 147 N.C. App. 138, 140, 554 S.E.2d 10, 12 (2001), disc. review denied, 355 N.C. 211, 559 S.E.2d 801 (2002). “On appeal, this Court must view
The State contends that only the September 1991 Agreement is a valid contract. We agree. OSBM had no authority to enter into the August 1990 Agreement since the voters of North Carolina had not yet approved the bond referendum authorizing the bond issuance. See Whitfield v. Gilchrist, 348 N.C. 39, 42, 497 S.E.2d 412, 415 (1998) (the State is liable only for “valid” contracts that are “ ‘authorized by law’ ”) (quoting Smith v. State, 289 N.C. 303, 322, 222 S.E.2d 412, 425 (1976)). However, in September 1991, the State entered into a second agreement with plaintiff, the September 1991 Agreement. By that time, OSBM had authority to enter into agreements on behalf of the State concerning the construction of prisons under the Bond Act, since the North Carolina voters approved the Bond Act on 6 November 1990 and the General Assembly ratified the Revenue Act on 13 July 1991, which expressly granted authority to OSBM to enter into contracts on behalf of the State with respect to “facilities authorized for the Department of Correction.” § 239(f), ch. 689, 1991 N.C. Sess. Laws 1894, 2127.
We next review whether OSBM had authority to enter into a contract for the $87.5 million portion of the Bond Act, in addition to the $103.4 million covered by the September 1991 Agreement. Plaintiff argues that section 239(f) of the Revenue Act granted OSBM the ability to contract for all prison facilities under the Bond Act, and that no language in the Revenue Act limits this authority. Section 239(f) states that
[w]ith respect to facilities authorized for the Department of Correction, the Office of State Budget and Management may contract for and supervise all aspects of administration, technical assistance, design, construction or demolition of prison facilities in order to implement the providing of prison facilities under the provisions of this act....
Id.
The State asserts several arguments as to why the attempt of OSBM to enter into a contract covering the $87.5 million was invalid. The State first argues that it could not enter into a contract for the $87.5 million without a legislative appropriation already in place. In
The State contends that because of this language, the September 1991 Agreement by its terms “tied [plaintiffs] performance of duties for that portion of the bond program to subsequent legislative enactments.” The State attempts to expand the language in the September 1991 Agreement to encompass any subsequent legislative enactments. We disagree with this characterization. The plain terms of the above cited language limit plaintiff’s ability to perform the September 1991 Agreement only in that plaintiff could not perform as to the remaining $87.5 million until the General Assembly appropriated those funds. If the General Assembly had not appropriated the funds, then plaintiff could not have performed on the remainder of the $87.5 million. Despite several interceding legislative enactments affecting the ability of the General Assembly to appropriate the bond program’s remaining funds, and the transfer of State oversight to OSC, the General Assembly did appropriate the $87.5 million on 24 July 1993. According to the terms of the September 1991 Agreement, plaintiff was entitled to perform its duties for the $87.5 million portion of the Bond Act upon appropriation.
The State next argues that OSBM did not have authority to enter into the portions of the September 1991 Agreement in which services covering the $87.5 million were addressed. “Only when the State has implicitly waived sovereign immunity by expressly entering into a valid contract through an agent of the State expressly authorized by
As discussed above, the State had the power to authorize agencies to enter into contracts concerning the $200 million under the Bond Act. Plaintiff argues that the General Assembly, through section 239(f) of the Revenue Act granted this authorization to OSBM. The State essentially argues that OSBM was not expressly authorized to enter into a contract for the $87.5 million. There is no dispute that the legislative enactments claiming to prevent agencies from contracting for services under the $87.5 million were enacted well after the effective date of the September 1991 Agreement. Further, it is undisputed that no such explicit limitations as those in the 1992 Appropriations Act were present in legislation at the time the September 1991 Agreement was executed. The facts surrounding the circumstances of what legislative enactments were in place at the time the September 1991 Agreement was executed are not in dispute. The determinative issue is whether section 239(f) of the Revenue Act granted authority to OSBM to enter into contracts involving the entire $200 million under the Bond Act. While the language of section 239(f) could have been drafted more clearly, we interpret the section to grant authority to OSBM to contract for the entire $200 million. Therefore, as a matter of law, the portion of the September 1991 Agreement governing the $87.5 million was part of a valid contract, authorized by law. The State is therefore not entitled to summary judgment.
The State argues that when the General Assembly finally appropriated the balance of the bond funds, it did so through OSC, not OSBM, and that this appropriation to an alternate state agency rendered invalid any potential authorization through the September 1991 Agreement. The State in effect argues that because OSBM entered into the contract on behalf of the State, that by transferring authority to enter into such construction contracts, as well as authority to manage the prison construction project from OSBM to OSC, the State does not have to honor the construction contract with plaintiff that it entered into through OSBM. We disagree.
The September 1991 Agreement contains language that specifically encompasses the entire $200 million, including the $87.5 million at issue in this case. OSBM entered into this contract with plaintiff;
Plaintiff was informed by Dorman that it would no longer be used as the project manager for the remaining portions of the construction project, despite the September 1991 Agreement. It is undisputed that the State did not use plaintiff as program manager for the remaining $87.5 million under the Bond Act. “[W]hen the State has implicitly waived sovereign immunity by expressly entering into a valid contract through an agent of the State expressly authorized by law to enter into such contract ... a plaintiff [may] proceed with a claim against the State upon the State’s breach.” Whitfield, 348 N.C. at 43, 497 S.E.2d at 415 (citing Smith, 289 N.C. at 322, 222 S.E.2d at 425). As determined above, the State had entered into a valid contract, authorized by law. The State’s action in not allowing plaintiff to perform the remainder of the September 1991 Agreement was a breach of that contract, for which plaintiff is entitled to damages.
The State argues, however, there are affirmative defenses that prevent plaintiff from recovering as a result of the State’s failure to use plaintiff as project manager for the $87.5 million portion of the construction project. The State argues a mutual mistake of fact as a defense barring plaintiff’s breach of contract claim. As this Court stated in Lancaster v. Lancaster,
[i]t is well established that the existence of a mutual mistake as to a material fact comprising the essence of the agreement will provide grounds to rescind a contract. See Mullinax v. Fieldcrest Cannon, Inc., 100 N.C. App. 248, 251, 395 S.E.2d 160, 162 (1990). “A mutual mistake of fact is a mistake ‘common to both parties and by reason of it each has done what neither intended.’ ” Swain v. C & N Evans Trucking Co., Inc., 126 N.C. App. 332, 335, 484 S.E.2d 845, 848 (1997) (citation omitted).
138 N.C. App. 459, 465, 530 S.E.2d 82, 86 (2000).
to justify a recision of a contract for a mutual mistake of fact, the mistake must concern facts as they existed at the time of the making of the contract; reliance on a prediction as to future events will not support a claim for recision based on mutual mistake of fact.
Opsahl v. Pinehurst Inc., 81 N.C. App. 56, 62, 344 S.E.2d 68, 72 (1986), disc. review improvidently allowed, 319 N.C. 222, 353 S.E.2d 400 (1987) (citations omitted). The transfer of authority to administer the prison construction project from OSBM to OSC was the type of “future event” that does not support a claim of mutual mistake of fact.
However, the State argues that the parties were mistaken as to whether OSBM originally had authority to enter into the portion of the September 1991 Agreement purporting to cover the $87.5 million. As discussed above, the State had authority to authorize an agency to enter into a contract for the remaining $87.5 million since it was contingent on those funds being appropriated. Further, we have already determined that OSBM was expressly authorized by the State to enter into a contract that encompassed the $87.5 million portion of the Bond Act on 18 September 1991. Therefore, the State’s defense based on mutual mistake of fact is without merit.
The State next argues “the affirmative defense of unjust enrichment.” Unjust enrichment, however, is a quasi-contractual theory of recovery, not an affirmative defense. Booe v. Shadrick, 322 N.C. 567, 570, 369 S.E.2d 554, 556 (1988). Further, unjust enrichment applies in the absence of a contract. Lagies v. Myers, 142 N.C. App. 239, 254, 542 S.E.2d 336, 345, disc. review denied, 353 N.C. 526, 549 S.E.2d 218 (2001) (citation omitted). The State’s attempt to argue unjust enrichment as a defense to its own termination of a contract is misplaced. The State’s argument of an affirmative defense of unjust enrichment is also without merit.
In summary, we hold that: (1) the terms of the September 1991 Agreement covered the entire $200 million of the Bond Act; (2) based
We need not address plaintiff’s remaining assignments of error in view of our above determinations.
Reversed and remanded.
