Lavanway v. Cannon

37 Wash. 593 | Wash. | 1905

Mount, C. J.

Respondents brought- this action in the court below to foreclose a mechanics’ lien, and for other relief. The complaint, in substance, alleges, a contract with appellants to construct a certain building in Seattle; a compliance with all the terms of the contract; a balance amounting to $5,250.80, due thereon from appellants; and a lien for that amount, properly filed, against the building and the land on which the building is located. Tor a separate cause of action, the complaint alleges, that the superintendent of the work, appointed by, and acting for, appellants, was incompetent and unfit to perform his duties, which fact was known to appellants; that such superintendent interfered with and delayed the work of respondents under the contract, by unnecessarily requiring changes and alterations, and then requiring the same to be changed again to the original condition; by which respondents were damaged. It further alleges that appellants failed and neglected to have the foundation ready for respondents at the specified time, and that damages were caused thereby. It further alleges that appellants failed to furnish certain materials as agreed, and that respondents were damaged thereby. Other damages of this character were alleged, amounting in the aggregate to $3,100. The prayer of the complaint was for a decree foreclosing the lien for $5,250.80 and costs, and for a judgment for damages, and for general relief.

Appellants filed a motion to strike the second cause of action stated in the complaint, upon the ground that two causes of action had been improperly joined. This motion was denied, and a demurrer was then filed, based upon the same ground, which demurrer was also denied. The appellants then answered, denying the allegations of the *596complaint, and also stating several separate defenses, one of which — and the only one necessary to be considered now —was that the contract provided that respondents should pay all claims for labor and material furnished by them, that the Washington Cornice Company had not been paid for certain materials furnished, and had filed a lien upon the building for the sum of $799.90, which was due and unpaid. Respondents in reply denied all the facts alleged in these several defenses.

Appellants then moved the court to require the respondents to make the Washington Cornice Company a party to the action. This motion was denied. Subsequently the ease came on for trial upon the issues, before the court and a jury, the jury being called as advisory upon the first cause of action, and to pass upon the question of damages alleged in the second cause of action. The jury, after hearing all the evidence in the case, found in favor of appellants as to the second cause of action, and, in answer to special questions upon the first cause of action, found that there was due respondents upon the original contract price, $2,000, and for extras, $800. The court thereafter disregarded the special findings of the jury upon the first cause of action, and found that respondents were entitled to the sum of $4,328, upon the first cause of action, and entered a decree foreclosing the lien for that amount, together with attorney's fees and costs, but dismissed the case as to the second cause of action stated in the complaint. The appeal is prosecuted from this decree.

It is contended that the lower court erred in denying the motion to strike, and in denying the demurrer, because actions ex contractu cannot be joined with actions ex delicto. Lengthy arguments are made in the briefs upon this question. But it is not necessary to decide it in this case, because, even if the second cause of action was improperly joined, both the jury and the court found in favor *597of appellants upon this canse, and a judgment was finally entered dismissing as to it. The appellants have not been injured by the joinder, and cannot now complain that it was not stricken upon their motion. If the court had considered this second cause of action, and found upon it in favor of the respondents, it would then be. necessary for us to decide the question presented. Where it is entirely eliminated by a decree in favor of the appellants, there can be no error of which the appellants may complain.

It is next contended that the lower court should have found upon the facts in favor of appellants, for three reasons: (1) That the contract required certificates from two architects showing completion of the work, while the evidence shows that such certificate was signed by but one of these architects; (2) that the contract provided that the respondents should pay all claims which might become liens upon the property before final payment should become due; and (3) that the evidence is not sufficient to support the findings in favor of the respondents. This last reason is based upon the first two stated.

Upon the first of these points, the architects named in the contract, Donnellan and Donahue, were copartners, engaged as architects at the time the contract was entered into. Shortly after that time this copartnership was dissolved, and the appellants refused to permit the architect Donahue to superintend or direct the construction of the building, or assist therein in any way, and he did not do so. The whole work was carried on under the sole direction of the other architect, Mr. Donnellan, and both the appellants and the respondents acquiesced therein. Appellants accepted Mr. Donnellan’s certificates of estimates during the progress of the work, and paid the same without objection. While the contract provided that estimates and certificates of work done should be issued by P. J. Donahue and J. J. Donnellan, supervising architects, yet *598this provision could be waived by common consent, and no doubt was waived, under the circumstances stated, so that Mr. Donnellan was the only one who was authorized to issue certificates required by the contract. Fitts v. Reinhart, 102 Iowa 311, 71 N. W. 227; Griffith v. Happersberger, 86 Cal. 605, 25 Pac. 137, 487; Smith v. Alker, 102 N. Y. 87, 6 N. E. 791; 9 Cyc. 646.

IJpon the second point, the contract provides:

“And it is further understood and agreed that,, upon the completion of said work on said building, and within ten days thereafter, upon a certificate issued by the architects, that said work has been completed in accordance with said plans and specifications, and that the said second party has done and performed his said contract in every particular, and upon a showing made that there are outstanding no claims by reason of work performed, or material furnished,, which could be made the basis of a lien upon the said building, said first party agrees to pay to said second party the balance remaining due and unpaid on said contract to said second party. It is further agreed that should there be any claims outstanding on account of labor performed, or material furnished, which might be made the basis of a lien upon said building, said first party shall have the right to retain, out of any payment due or thereafter to become due, .an amount sufficient to discharge such claims or obligations. And should there prove to be any such claims, after all payments are made, the said second party shall refund to the first party all moneys that the latter may be compelled to pay in discharging any lien on said premises made obligatory in consequence of said second party’s default.”

The trial court found, and there is evidence to support the findings, that the building was completed; that the architect, in charge thereof had issued, in good faith, his final certificate to the effect that the building had been completed in accordance with the contract, and that respondents had fully performed the contract, and that there *599was still due the respondents thereon the sum of $3,988 (this amount did not include extras for which a separate allowance was made); that thereupon respondents made a showing to appellants that there were no claims outstanding which could be made the basis of a lien upon the said building, and exhibited receipts and vouchers for all labor performed and materials furnished for said building to and for said respondents, showing that said materials and labor were fully paid for. This was certainly all that was required of the respondents, under the provisions of the contract, to show that the balance of the contract price was then due.

It is alleged in the answer of appellants that the Washington Cornice Company had filed a lien upon the building for materials and labor furnished in the construction of the building, claiming a balance due of $799.90. The answer does not state when this lien was filed, but it appears .to have been filed after the respondents’ action was commenced. Appellants, upon filing their answer, moved the court to require the respondents to make the Washington Cornice Company a party to this action. This motion was denied, and, we think, correctly so, because the statute, at Bal. Code, § 5910, provides that all persons who prior to the commencement of the action have filed lien claims against the same property shall be joined as plaintiffs or defendants. Those who file claims of liens subsequently, of course cannot be made parties. Subsequent lien claimants, by the terms of the statute, are not permitted to bring an independent action. They must apply to the court to be joined as parties thereto by way of intervention. The Washington Cornice Company did not so apply.

Numerous errors are alleged in the instructions given by the court to the jury. It is not necessary to consider these', because the only question which the jury passed upon was the appellants’ liability upon the second cause of action. *600This finding was in appellants’ favor. The other questions are reviewahle here de novo, and upon them w© are satisfied with the findings of the lower court.

^Respondents ask for a further allowance in this court for attorney’s fees here. It has not been the practice of this court to allow independent attorney’s fees in this court, in cases of this character. We think such allowances are more properly within the jurisdiction of the trial court, to be allowed at the time of the trial. Four hundred dollars was so allowed, and we think that amount was sufficient. The request is therefore denied.

There is no error in the record, and the judgment of the lower court is affirmed.

Dunbar, Hadley, and Fullerton, JJ., concur.

Rudkin, Root, and Crow, JJ., took no part.