256 Mo. 133 | Mo. | 1914
— This controversy arises upon a surety bond given to secure plaintiffs against loss by reason of any failure of the defendant contractors to perform their contract to erect a building in St. Louis. The trial court gave judgment for the defendant surety company. The questions presented relate solely to the efficacy of certain facts to release the surety from its obligation. Respondent company is in the business of acting as surety, charging a premium therefor. It had received compensation for becoming surety on the bond in suit.
The defenses and findings upon which the surety was released below will be examined in order. They must be vieAved in the light of some applicable general principles.
“The doctrine that a surety is a favorite of the law, and that a claim against bim is strictissimi juris, does not apply where the bond or undertaking is executed upon a consideration by a corporation organized to make such bonds or undertakings for profit. While such corporations may call themselves ‘surety companies,’ their business is in all essential particulars that of insurers. Their contracts are usually in the terms prescribed by themselves, and should be construed most strongly in favor of the obligee. ’ ’ [32 Cye. 306.]
The contract provided: “Should any alteration be required in the work shown or described by the drawings or specifications, a fair and reasonable valuation of the work added or omitted shall be made by the architects, and the sum herein agreed to be paid
The referee’s finding on this phase of the case is that alterations in the work were made from time to time but that the architects did not pass upon these changes and determine, before each was made, the sum to be added or deducted on account of it; that the changes were not made upon the written order of the architects, nor was arbitration asked by the contractors. He finds that in July, after the building was nearing completion, the contractors and the representative of plaintiffs and local superintendent for the architects, went over the building and made a list of changes; having made the list, the parties, agreed upon the sums to be added and subtracted. The list of changes and agreed allowances were put in writing and signed by the parties and approved and signed by the architects. The net result was the enhancement of the contract price by $391 and the payment of that additional sum to the contractors. The referee concludes his finding on this branch of the case thus: “So far as. the allowances made in this exhibit to the defendants Renshaw, for changes and alterations, are concerned, the referee believes and finds they were fair and reasonable and not in excess of their true value; but as already suggested, they were not agreed upon in the manner provided for in the contract. ’ ’
On his view, the departures from the contract made were (1) the failure of the architects to fix the increase or decrease of the contract price before the change was made; (2) that the changes were not made upon the written order of the architect; and (3) that arbitration was not requested by the contractors.
In view of the principles above announced, it appears the learned referee applied too strict a rule on this branch of the case. The surety lost nothing, its risk of loss was in no way increased and, in fact, in the end it received the exact protection to which the contract entitled it.
In Chapman v. Eneberg, 95 Mo. App. 127, there was an express provision in the contract to the effect that “no work of any description is to be considered as extra work unless the same shall have been understood and agreed upon in writing before such work is commenced.” That case is, therefore, unlike the one at bar. The contract provision and the facts in Furniture Co. v. Toll, 133 Mo. App. l. c. 407, resemble closely those in this case, and the decision therein is in full accord with the conclusions reached above.
The contract price was $26,838 and was to be paid in twelve installments, each falling due when the work
In this connection the referee finds that the certificates or orders given by the architects were in the following form:
“No. 1. Office of J. B. Legg, Architect.
St. Louis, December 29, 1902.
Missouri Botanical Garden:
Pay to the order of Renshaw & Son one thousand and five hundred ($1500) x-100 dollars, on account of their contract for building your Eddy factory building-, S. W. Corner Market and Main streets. $1500.00.
J. B. Legg, Architect.”
The referee finds the orders sufficiently identified plaintiffs as trustees and sufficiently identified the building under construction but holds the failure of the architects to specifically certify that the work, upon the performance of which the payment became due, had been done to the satisfaction of the architects, released the surety, and also finds that certain payments were made in advance of the giving of the orders, and for this additional reason holds the surety was. released.
The referee expressly found that all the money paid went into the building “in the shape of work done or material furnished. ”
In Wyckoff v. Meyers, 44 N. Y. l. c. 144, the contract provided for final payment upon the architects’ certifying that the work “was completely finished.” The architects certified simply that the final payment was due under the contract, and- this was held sufficient.
The court said (1. c. 226): “The certificate does not state, in terms, that the work is to the satisfaction of the superintendent, but it fixes the value thereof at the contract price, and states no objection thereto. This, we think, is equivalent to a statement that the work was done to his satisfaction.”
Other cases to a like effect are Anderson v. Meislahn, 12 Daly, 149; Tilden v. Buffalo Office Building Co., 50 N. Y. Supp. (App. Div.) 511.
Those were suits against the owner, and the certificates were held to support an action by the contractor. They are in point here because if a certificate is sufficient to enable the contractor to force the owner to pay, the contractor’s surety could not maintain that they were insufficient to the extent that payment not under compulsion would have been unjustifiable.
No particular form of certificate is required in a case like this; and no fraud on the part of the architects having been so much as suggested and the money paid having all gone into the building, as the referee finds, we hold the certificates in this case were sufficient in the circumstances and their informality did not warrant judgment for the surety.
The additional question in this connection is as to-the effect to be given the advancements, loans or payments made before the certificates were given by the architects.
The date of the first certificate was December 29, 1902.
The referee finds that on December 4th the contractors received from Mr. Cunningham, representing plaintiffs, $500; on December 13, $300, and on December 22, $300 — a total of $1100. When the contractors
These advancements were made without the knowledge of the surety, and the referee held the surety was discharged thereby.
When installments under a contract secured by an accommodation surety are paid before they are due and without the surety’s consent, the rule is well established that the surety is thereby released. In such case the injury to the surety is presumed. This is the result of the doctrine that such a surety is a favorite of the law. The retention of installments by the obligee until the work reaches the prescribed stage is said to furnish an incentive to the contractor to complete the work within the prescribed time.
Ought a presumption of injury or that the surety’s risk was increased be indulged in this case? The referee finds expressly that all these sums went to pay for labor and materials actually employed in the construction of the building. This finding conclusively disproves injury as a fact. That being true, and the presumption of injury under like circumstances in favor of an accommodation surety being indulged because of the rule that such a surety is a favorite of the law and that rule being inapplicable to a surety whose engagement is undertaken for compensation, no presumption of injury found as a fact not to have occurred ought to be indulged to release such a surety.
There is authority supporting this view. [American Surety Co. v. Scott & Co., 18 Okla. l. c. 272, 273;
The surety in this, case is in no position to complain that the tenderness courts see fit to show the .accommodation surety, always an object of the greatest solicitude, is not shown to it. Its situation is entirely -different. It is to be dealt with in the light of its. real relation to the contract — an insurer of its performance.
The learned referee also held the surety discharged .on a third ground.
The contract provided that the building should be «completed May 1, 1903. April 28> plaintiffs wrote the surety company stating that while the work was pro.-gressing satisfactorily yet it appeared that the payments to the contractors, as. they matured under the contract, were insufficient to meet their labor bills in 'the early stages of the building, and asking permission
On May 22 the surety company wrote plaintiffs giving permission to pay “material bills now due, upon the order of” the contractors and explaining the delay in replying by saying that it had been caused by delay in securing consent of the surety’s indemnitors. The contractors continued their work, and on June 30 plaintiffs, by their secretary, wrote the surety company, among other things, as- follows:
“We desire now to further notify you that the said Renshaw & Son are unable to perform all the conditions of their contract. First, the said contractors are unable to make the payments for labor employed and material furnished for the said building as it progresses, and in order to prevent any filing of lien claims therefor we have found, and still find it necessary, to make payments to the sub-contractors, material men and laborers directly, for their said material and services, in advance of the regular installments of payments to contractors, and to deduct the same from the installments of payments, accruing thereafter, to the said contractors.
“While we are empowered under the contract to make such payments and such deductions, we wish to notify you of the inability of the contractors for lack of adequate means, to perform their contract, forcing us to take such steps. We have prepared a list of all the liabilities of said contractors remaining unpaid and required to be paid, for the completion of said building so far as we can ascertain, which list we are prepared to submit to you for your inspection whenever desired.
“You are further notified that by the terms of their contract, in the 6th clause thereof, the building was contracted to be finished on the first day of May, 1903. It was. not finished at said date and will not be finished before about the first day of August, 1903. We understand that the contractor claims that some part*148 of this delay was due to causes excepted iu the contract, but as no formal claim has been filed by them for such allowance, we cannot state it with more particularity.”
To this letter the surety company did not reply and in no way objected to its sufficiency until answer filed.
About August 15 the contractors ceased work on the building, and plaintiffs caused some work to be done on the building, but before the building was fully completed they wrote the surety company, September 12, referring to their letter of June 30, and stating that certain work remained to be done; that they had paid out all but about $100 of the contract price, on the contractors’ orders, for labor and materials; that there remained due and unpaid bills for material used in constructing the building and to subcontractors, amounting to $7200 to $7500, according to an itemized and verified statement enclosed.
September 16 the surety company replied stating they would take the matter up< with their indemnitors and stating they would attempt to. have the contractors “straighten the matter out at the earliest possible moment.”
October 12 plaintiffs again wrote the surety company saying the building was still uncompleted and that they had notified the contractors they must proceed within three days or they, plaintiffs, would take charge and finish the work, as the contract contemplated they might. They also notified the surety that lien claimants were serving notices and that costs would accumulate unless the matters were attended to.
In response to this letter the surety company wrote:
“Your favor of Oct. 12 with reference to bond executed for Renshaw & Son received this p. m., in which you desire an answer by Wednesday noon as to*149 whether we desire to complete the building and pay the claims mentioned in your letter.
“Reply, we beg to say that we have conferred with Messrs. Renshaw & Son, as well as our indemnitors, concerning the completion of the building, and we are informed by them that they at one time sent men to the building for the purpose of completing the same, and that they were ordered away by your superintendent. Under these circumstances this company is powerless ait the present time to either complete the building, or to pay any alleged claims for material or otherwise.
“You can readily, no doubt, understand our position; that were we to do any work on the building, or pay any claims alleged to be due, without being directed by Renshaw & Son, or our indemnitors assenting thereto, that the latter would be released from any liability that might possibly accrue in the future to this company. This is about all we can say at this time, and of course you are at liberty to take such action with reference to the matter as you may see fit.”
The referee finds that the sums paid by plaintiffs for labor and materials which went into the building exceeded the contract price by $7473.34.
Plaintiffs are not contending for any recovery by reason of the delay of the contractors in finishing the building. The referee made a separate finding to the effect that in no event could the surety be held for any amount for such delay.
In such circumstances there is an abundance of authority for the view that failure to notify the surety of the contractors’ failure to complete the building in contract time does not release the surety. [Pulaski Hall Assn. v. Am. Surety Co., 123 Minn. l. c. 225, 143 N. W. l. c. 716, 717, and cases cited; American Surety Co. v. Scott & Co., 18 Okla. l. c. 271.]
So far as concerns sums, expended to complete the building after the contractors refused to proceed and the surety attempted to wash its hands of the matter, no notice was required. There was no default of the contractors affecting these sums save their general default in failing to complete the building, and of this, notice was given before the payments were made.
The question is as to the sufficiency or necessity of notice of the failure of the contractors to pay the material and labor bills except such as plaintiffs paid in completing the building after they took charge.
The contract provided, among other things: “And should there prove to be any such claim after all payments are made, the contractors shall refund to the owner all moneys that the latter may be compelled to pay in discharging any lien on said premises, made obligatory in consequence of the former’s default. ’ ’
In a case very like this, so far as the question under consideration is concerned, it was held (Lakeside Land Co. v. Empire State Surety Co., 105 Minn. 213) that the entire failure to give notice of a failure to complete the work in.contract time and of failure of the contractors to pay certain labor and material bills, was not sufficient to absolve the surety.
The court said: “That the strict rule of construction is not applicable with reference to bonds issued by surety companies has become very well settled in the
To the same effect are some of the cases already cited and, also, Heffernan v. U. S. Fidelity & Guaranty do., 37 Wash. 477.
In view of this rule, it seems evident that the mere failure of plaintiffs to notify the surety of the unpaid claims for labor and materials as each debt was incurred by the contractors could not release the surety. Such.claims, in excess of the contract price (such only being involved here), plaintiffs had the right under the contract to pay in order to protect the property, and it was then the duty of the contractor to refund. Of these claims the surety was notified, and then attempted to step out of the matter. Every cent paid went into the building, and the contractors did not refund. This was the actual default under the contract so far as the claims now being discussed are concerned. Of this default the surety company had notice, both from plaintiffs and from the contractors, but refused to act.
The cases of National Surety Co. v. Long, 125 Fed. 887, 60 C. C. A. 623; United States Fidelity & Guaranty Co. v. Rice, 148 Fed. 206; and Beech Grove Imp. Co. v. Title Guaranty & Surety Co., 50 Ind. App. 377, 98 N. E. 373, are not in point for reasons pointed out in Lakeside Land Co. v. Empire State Surety Co., supra.
Many other decisions supporting the conclusions above announced will be found cited in Van Buren County v. American Surety Co., 137 Ia. 490.
— The foregoing opinion of Blair, C. is adopted as the opinion of the court.