57 Minn. 231 | Minn. | 1894
Action on a contract of plaintiff with the city of Lakeside (since consolidated with the city of Duluth) “for the grading and otherwise improving” an avenue in said city. The only controversy arises on a counterclaim of defendant for a failure to complete the work by the time specified in the contract. The contract stipulates, as damages, $25 for each and every day the contractor shall be in default in completing the work. The fact that it was not completed by the time specified is admitted, but plaintiff claims the failure was caused by the neglect to furnish certain culvert pipe which, as he construes the contract, it was the duty of the city to furnish. In the contract is this clause: “And the party of the second part (the contractor) hereby agrees to receive the following prices for furnishing all the materials not found in the work (except such materials as shall be furnished by the city of Lakeside, as stated in this contract), and for labor, and for use
It is evident from the above quotation that some of the material was to be furnished by the city; and there is nothing in the contract to point out what material it is to furnish, unless it is to be found in the table or list' of items. In that table are fifteen items, each (excepting two) so worded as to indicate that the contractor is to furnish the material and do the work. Those two are stated thus: “Laying 15 culvert pipe, lin. ft. .12” “Laying 24 culvert pipe, lin. ft. .25” Taking the fact that the specification of each other item includes the material and work, while the specification as to those two items seems limited to doing the work, to wit, “laying” the pipe, it is very suggestive that the pipe is the material which the city is to furnish. To state it most favorably to the city, it makes a case of ambiguity such as to let in the doctrine of practical construction by the parties. It was so practically construed; the city furnishing the pipe, and its engineer, knowing that fact, furnishing an estimate certifying that the contractor had completed his contract, and allowing him, for laying the pipe, the prices set down in the list.
There can be no question of the engineer’s authority to construe the contract. It requires of him many things which he could only do by construing it. The engineer’s estimate was also approved by the council. The facts showing the practical construction were undisputed, so that the admission of oral evidence of a prior agreement consistent with that construction, if erroneous, could not prejudice.
The stipulation for damages for delay could not be applied to a delay caused by the city itself. To so apply it would enable the city to profit, at the rate of $25 per day, from its own wrong.
The same may be said of the clause in the contract requiring the contractor, if he desired an extension of time to complete his contract, by reason of “any hindrance or delay from any cause whatever,” to give notice of the cause of detention to the engineer, to be reported to the council, it to “determine the amount of time that may compensate for the detention.” The phrase “from any cause
From the evidence, the jury might find the cause of failure to complete the contract by the stipulated time was the delay of the city in furnishing the culvert pipe.
Order affirmed.
(Opinion published 58 N. W. 902.)