Haynes, Spencer & Co. v. Second Baptist Church

88 Mo. 285 | Mo. | 1885

Black, J.

Plaintiff and defendant, both corporations, entered into a contract by which plaintiff - agreed to make, finish and put in place certain fixtures in defendant’s building at St. Louis. The work was- to be done according to plans to the entire satisfaction of the ■superintendent and building committee, and to be completed by the first of December, 1878. under a forfeiture of ten dollars for each day’s delay. As a full compensation, defendant agreed to pay $4,800 on the completion of the work and acceptance of the same. The building was without fault of either party destroyed by an accidental fire on January 2, 1879. At that time the pews in the gallery and pulpit screen had' been attached to the building. The- other fixtures, including the pews for lower or audience room, were in the building on the floor and workmen were engaged in putting them in place. The building was in the possession of defend*289ant, had been erected by separate contracts for the different departments of work, and had been by defendant from time to time insured. This is a suit for the value of the work and materials in place and on the floors. The defence is a failure to complete the work according to the contract.

1. Besides the fact that the work was in progress after the date fixed by the contract for its completion, it also appears that by agreement between the parties the backs of a few of the pews were to be altered in some respects at the cost of the defendant. It does not appear whether the time for completing the work was extended by agreement or by acquiescence. Neither the extension of the time for the completion of the work, nor the agreed changes as to those qoews, affected the contract in its other provisions. The contract in all other respects remained in full force. Plaintiff cannot simply because of this delay and these alterations abandon the contract and sue for the value of the work. 19 Pick. 275.

2. Some reliance for a recovery is also placed upon an alleged acceptance, and in support of this we are cited to Lord v. Wheeler, 1 Gray, 282. We do not regard the facts of that case analogous to this. There, when the repairs were substantially done, and before the fire, the defendant by his tenant entered into and occupied the house and so used and enjoyed the labor and materiál, which use and enjoyment it was held, were a severance of the contract, and an acceptance pro tanto. Here there is no pretense that the edifice was even used for any other purpose than that of construction, and that use is contemplated by the contract. The contract also determines by whom and how the accejptance shall be made. The duty to pass upon the work did not arise until completion. There is, therefore, nothing in the case upon which to base any claim upon the ground that the work or any part of it had been accepted.

3. Where a contractor undertakes to build a house *290upon the land of another, and the house before its completion is destroyed by fire without his fault, he is not thereby relieved from his obligation to fulfill the contract. The duty in such- a case is to be distinguished from one imposed by law. The obligation to build is founded upon, and is his own voluntary contract, and Its non-performance is not excused by inevitable accident. Adams v. Nichols et al., 19 Pick. 275; Tompkins v. Dudley, 25 N. Y. 272; School Dist. v. Dauchy, 25 Conn. 530; School Trustees v. Bennett, 3 Dutcher, 515; Dermott v. Jones, 2 Wall. 1. In all of these cases the contract was to build a house entire and complete and it is apparent they are quite unlike the contract in question here. There are two lines of authorities which have a direct bearing upon the question in hand. In Addison on Contracts, volume 2, page 554 (Morgan’s Ed.), it is said: “Where a.man contracts to expend material and labor on buildings belonging to and in the occupation of the employer to be paid for on completion of the whole, and before completion the buildings are destroyed by accidental fire the contractor is excused from completing the work but is not entitled to any compensation for the work already done, which perished without any default of the employer.” The contractor in Appleby v. Meyers, L. R. 2 C. P. 651, agreed to provide and erect certain machinery for a fixed sum and keep the same in repair for two years. The rule applied is. as stated in the text of Addison. In Brumby v. Smith, 3 Ala. (N. S.) 123, the agreement was to complete the carpenter’s work on a house of the employer for a specified sum to be paid when the work was completed, the material to be furnished by the enrployer.. The house was destroyed by fire a few days before completion of the work, and it was held the carpenter could not recover for work done. The ruling is placed upon •the ground that the contract was entire, and by its terms the labor was not to be'paid for until the work was com*291pleted. But in the same state it is held where the work is to be paid for in installments, then the mechanic may recover the installments due at the time of the destruction of the work. Partridge v. Forsyth, 29 Ala. 200.

On the other hand some of the courts of the states have expressly declined to follow the rule announced in Brumby v. Smith, and others apply rules in like cases inconsistent therewith. In Hollis v. Chapman, 36 Texas 11, the mechanic agreed^to furnish the materials and do the carpenter’s work on two brick buildings then in process of erection for a specified sum and to turn them ■over complete, with all possible dispatch. The court said : “This agreement could not possibly have been an ■entire independent contract, for it was • dependent on many circumstances, such as the erection of the walls to receive the carpenter’s work, the plastering, glazing, painting, etc., and there was no stipulation in regard to the time of payment.” So in Cleary v. Sohier, 120 Mass. 210, where a workman had contracted to lath and plaster a building for a certain sum per yard, and he had lathed the building and put on one coat of plastering, when without his fault it was destroyed by fire, it was held he could recover for the work done. There was no ■express agreement as to the time of payment. Cook et al. v. McCabe, 53 Wis. 250, is not unlike the two cases last cited, save that the work was to be paid for in part when completed and the balance at a designated time thereafter. That case concedes the general rule to be that one who undertakes to build a house must do so, and cannot recover for work done in case the house is destroyed by fire before completion, but it also holds that the rule is only applicable when the contract is not subject to any conditions expressed or .implied. See also Rawson v. Clark, 70 Ill., 656. In Niblo v. Binsse, Keyes, 476, the contractor agreed to furnish and put into a house then under construction, steam coils, etc., the work to be paid for as parts of the work were completed, *292another when the work was done and the residue when the work was tested and found sufficient. After the greater portion of the work had been done and several payments made, the building accidentally' burned. Recovery was allowed for the labor and material according-to the contract as far as the work had gone. ‘ The judgment in that case is not made to depend upon the fact, that the work was to be paid for in installments, but it is placed upon the express ground that the owner was. bound to have and keep the house in readiness to receive the work. Such a stipulation was not expressed in the contract, but it was held to be implied. The cases cited from the Supreme Courts of Texas and Wisconsin stand substantially upon the same ground.

Now in this case the fixtures were, it is true, to be put in place and completed to the satisfaction of the building committee, and to be paid for only when completed. But the contract is based upon the assumption, that the defendant would have its edifice erected and ready to receive the work. All this was a condition precedent to the performance of the contract by the plaintiff. The implied contract on the part of the defendant. was to have and keep the building ready to receive these' fixtures and to furnish room therein for them for such length of time as would reasonably be required to put-them in place. The agreement to do all this is as much a part of the contract, as if expressed therein in terms. This the defendant failed to do. Besides this the house was in the possession, control, care • and custody of defendant, and the plaintiff had nothing to do with its protection, further than to be without fault as to its own work. The contract was not, therefore, an absolute one to do the work at all hazards, but it was dependent upon the assumed and implied conditions before stated, conditions which the defendant was to perform and which it did not perform. According to the weight of the AmerU can authority such a contract is severable to the extent *293that tlie mechanic may. recover for work done np to the time of the lire. In this case the recovery should include the fixtures on the floor as well as those in place. The judgment of the court of appeals is, therefore, affirmed.

Norton, J., dissents. The other judges concur.