Hardaway-Wright Co. v. Bradley Bros., 51 So. 21

Hardaway-Wright Co. v. Bradley Bros.

51 So. 21 | Ala. | 1909

SIMPSON, J.

This is an action by the appellees against the appellant to recover damages for the breach of a contract by which the plaintiffs agreed to grade *599the roadbed of a certain part of a railway; it being claimed by the plaintiffs that after they had at great expense provided themselves with the necessary teams, laborers, and equipment, and had taken them to the place of performance, plaintiffs were first delayed a considerable time, with their teams, etc., on expense, and were finally prevented from carrying on the work, by reason of the fact that the defendant had not secured the right of way, nor surveyed and staked out the route, etc., and plaintiffs were forced to sell out their teams, etc., at a great sacrifice. One of the counts of the complaint claims for $586 for work done in accordance with the contract.

One of the plaintiffs, F. M. Bradley, being examined as a witness, testified that his brother had come from Atlanta, Ga., at the appointed time, with the teams, equipment, etc., and notified the defendant of his readiness to commence on the work in accordance with the contract, but that, by reason of the failure of the defendant to make the preparations for the work in accordance with the contract (stating the details), plaintiffs’ laborers, teams, etc., were kept unemployed for 10 days. He was then asked: “What was the reasonable value of the use and hire of your outfit for said 10 days?” This question was objected to by the defendant, and the objection overruled, which action of the court is made the subject of the first assignment of error insisted on. There was no error in the overruling of said objection. This item of damage was distinctly claimed in the complaint, the witness had testified to the delay, and the proper measure of damage was the value of the use or hire of the outfit for that time, or the profits that would have been realized out of the contract. The plaintiffs may prove both, and the defendant may protect himself by a charge to the effect *600that both are not recoverable. — 13 Cyc. 159, 160, 161; Watson v. Kirby & Sons, 112 Ala. 436, 446, 20 South. 624; Worthington & Co. v. Gwin, 119 Ala. 44, 51, 24 South. 739, 43 L. R. A. 382.

The court erred in overruling the objection by the defendant to the question to the witness F. M. Bradley, “If the plaintiffs had been allowed to do the construction work on mile 16, what profits would plaintiffs have realized?” This question called for a conclusion, which should be drawn by the jury, and not by the witness. The witness should testify to the facts going to show what it would cost to do the work, and by comparing this Avith the amount which was to be phid to plaintiffs for the work the jury should be left to reach the conclusion as to how much plaintiffs would have realized if they had been allowed to proceed with the work.— Danforth & Armstrong v. T. C., I. & R. R. Co., 93 Ala. 614, 620, 11 South. 60; U. S. v. Behan, 110 U. S. 338, 344, 4 Sup. Ct. 81, 28 L. Ed. 168.

The court erred in overruling the objection to the question to the witness M. J. Bradley, “What was the reasonable value of the use and hire of said teams and outfit from, the 13th of November to the 23d of November, 1907?” The only facts testified to by- the witness on this point were that on November 13th he left the camp Avhere plaintiffs were working and went to West Point, Ga., to try to collect for work done, and to get the time extended for completing the work on mile 16; that he could not get the pay for work done and time lost, and that they quit work on November 23d, because the stakes were changed and they were not paid for the woi*k. These facts would not warrant the conclusion that from the 13th to the 23d of November the teams and outfit were kept idle by any act of the defendant. ’ -

*601The court instructed the jury that “if the jury believe, from the evidence, that the plaintiffs accepted work on mile 15'until 16 was ready, and without any intention by the plaintiffs and defendant of modifying or altering the original contract, then the mere fact of accepting said work would not be an alteration of the original contract.” There was no error in this charge. The question of the construction and effect of contracts is a matter for the court, and it is also for the court to decide whether 'or not cértain facts amount to an alteration or modification of a contract, while the jury must decide whether or not these facts are proved. The evidence of the defendant is merely' that, as it had not been able to get mile 16 in a condition for plaintiffs to continue work thereon', it was agreed that during this delay plaintiffs would work on mile 15.. The original contract did not specify any particular date when work was to commence on mile 16, but only that it was to commence “as soon as possible,” and it would not be possible to commence work until the defendant had gotten that part ready, so that this agreement did not alter that part of the contract. Neither did it alter the remaining provision of the contract that the work was to be completed by the 15th of January, 1908, though, if plaintiffs had gone on with the contract on mile 16, and had been unable to complete it within that time, by reason of the delay caused by the defendant, it might have excused the plaintiffs from liability for not completing the work within the time.

There was no error in charging the jury that “if the jury believe that plaintiffs went to work on mile 15, without knowing that it was mile 15, but believing that it was the mile that they contracted for, this would not constitute a modification or abandonment of the contract.” The evidence on this point was that, when plaintiffs reported for work, the agent .of defendant *602put them to work on a part of mile 15, and they continued to work there for several days, thinking that they were working on mile 16. It requires no argument to show that the mere working at another point, by mistake, could not amount to an abandonment or modification of the original written contract.

Charge 3, requested by the defendant, should have been given. The contract provided that the 15 per cent, retained by the defendant should not be paid until proper proof was made “that all subcontractors, laborers, materialmen, and all persons, who might have a lien on said Bradley Brothers’ property for work done for, or for material furnished for, said Bradley Brothers for the carrying out of this contract have been fully paid, or their claims satisfactorily secured.” There was no proof in regard to these, matters, and consequently the 15 per cent, was not recoverable.

There was no error in the refusal to give charge 4, requested by the defendant. Besides being in had form, if plaintiffs were kept on expense up to the 12th day of October, on acc'ount of the defendant’s failure to comply with its part of the contract, those expenses were a proper subject of damages to be considered by the jury; but, as they could not recover both expenses and profits, the court could not instruct for a recovery of either. See authorities supra.

There was no error in the refusal to give charge 7, requested by the defendant. Besides being in bad form, the failure to prove the matters therein mentioned would affect only the 15 per cent, reserved, and not the entire claim for work done in count 3.

The judgment of the court is reversed, and the cause remanded.

Reversed and remanded.

Dowdell, ,C. J., and MoOlellan and Mayfield, JJ., concur.