Appellant B. H. Grube at' all relevant times was the record owner of lots 2, 3, 4, 5 and 6 in Block 25, Belmont Subdivision to the Town of Midland, Midland County, Texas. On January 1, 1952, he leased said property to Nick’s No. 2, a Texas corporation, for a period of twenty years commencing January 1, 1952 and ending on the last day of December, 1972. Nick’s No. 2 was a Texas corporation. It had an authorized cаpital stock of $1,000, $500 of which was paid for. By Section 4 of the lease the lessee agreed to make such improvemеnts and erect such building on the leased premises as should *253 be required for the uses the lessee desired to make of the premises, such improvements and building' to be made at the cost of lessee. By Section 5 of the lease all such buildings and improvements should vest in and become the property of lessor upon termination of the lease. It • was stipulated that such vesting was a part of the consideration for the execution of the lease by lessor. The lessee contracted with intervening аppellee John L. Stone for the erection of a mercantile • building on the leased premises, and Stone and a numbеr, of subcontractors who also intervened furnished material and labor to construct such building. No payments having been made by Niсk’s No. 2 the contractors ceased work on the building before it was completed. The lessor filed this suit because of lessee’s failure to complete the building with reasonable diligence and to carry insurance on the building as provided by the lease. The contractors intervened and sought a judgment against appellant for the" various amounts due them and a foreclosure of the constitutional mechanic’s lien against the property. Trial was to a jury. On answers to special. issues submitted the court rendered judgment in favor of Stone against Nick’s No. 2 and B. H. Grube for $45,855.54, and in favor of the intervening subcontractors for the resрective amounts due them against the intervenor John L. Stone, and ordered a foreclosure of a constitutional meсhanic’s lien in favor of John L. Stone against the leasehold estate created by the lease between Grube- and Nick’s Nо. 2, and also on the reversionary interest of B. H. Grube in the lots above described.
The jury’s finding and answers to. Special Issues Nos. 3 and 4 wеre as follows:
“Special Issue No. 3. Do you find from a preponderance of the evidence, if any, that the coursе of conduct if any pursued by defendant, B. H. Grube, subsequent to November 1, 1951, caused the store building to be - constructed by Intervenor Stonе on the land involved in this suit? Answer • Yes or No.
"“Answer Yes. ' .■
“Special Issue No. 4. Do you find .from a preponderance of 'the evidence, if any, that the course of conduct if any, pursued by defendant B. H. Grube," subsequent to November 1', 1951, misled the .Intervenor Stone into ■ believing ..that Nick’s #2 .had the right to- make such contract,; with reference to the. store building upon ' the property involved; in this suit, as would’create in favor of such ;Inter-, venor Stone a lien upon the entire property in question? . Answer Yes or . No. .. ,. ,. :
“Answer Yes.”
"It is not'seriously contended that in entering "into the
<■
contract with - Stone Nick’s Nо. 2' was acting as The- agent of Grube. Rather the contention is that Grube by entering into the lease with Nick’s No. 2, and • by -his' knowledge that the -building wаs be'i'ng constructed, and his acquiescence therein without ■ disclosing the unrecorded lease to Stone, caused the building tо -be erected on 'his land and thereby subjected it to the constitutional lien given to mechanics, ■ ar-tisans and- materialmen., This same contention was made and rejected in Cleburne St. R. Co. v. Barber, Tex.Civ.App.,
“(4) We simply hold that the Con- . stitution provides for a lien independent of the statute'on the estate of the , persoij causing the improvements to be erected, in this case the leasehold estate of Brown, and not the fee ownéd by Russell, because under the facts in this case the latter had no contract with appellant by which a lien' could be fixed. ‘ Strang v. Pray,89 Tex. 525 ,35 S.W. 1054 ; Ogburn Gravel Co. v. Watson Co. (Tex.Civ.App.)190 S.W. 205 , writ of error granted, affirmed *254 Watson Co. v. Ogden Gravel Co.,110 Tex. 161 ,217 S.W. 373 ; Wilson v. Sherwin-Williams Paint Co.,110 Tex. 156 ,217 S.W. 372 ; First National Bank of Paris v. Lyon-Gray Lumber Co., (Tex.Civ.App.)194 S.W. 1146 .”
Therefore we hold that no valid lien was created on Grube’s reversionary interest in the land here involved, absent any contract between Grube or his representative and any contractor furnishing labor or material for the building in question.
We also hold that neithеr the personal judgment against Grube nor foreclosure of a lien against his property can be sustained on the theory оf quantum meruit. Appellant states in his brief.that there is no evidence in the record to show the value of the lands owned by Grube prior to the commencement of the construction of the building in question, and no evidence to show the value of the land at thе time, the incompleted structure was abandoned. Appellee does not challange this statement. We have reаd the entire statement of facts and find no such evidence. Of course these values must be shown to establish the value of the labor and material furnished. The mere cost of such labor and material is-not enough. Also, it is apparent that at no time during the сonstruction of the building;in question was appellant Grube charged with notice that appellee Stone or any of the subcontractors were looking to him- for payment. The evidence is conclusive that ■ they were not. Although Grube was the record owner of the property, neither. Stone nor any of the subcontractors had any dealings with him during the five months while the building was being cоnstructed. Stone’s testimony is to effect that he was dealing with Mr. Nichols and Mr. Marlow. Therefore, another essential element to establish a cause of action in quantum meruit is lacking. Wyche v. Perrin, Tex. Civ.App.,
It is therefore our conclusion that the judgment should bе reformed; that insofar as it awards any personal recovery against B. H. Grube, and insofar as it attempts to establish a constitutional mechanic’s lien against his property, being his reversionary interest in Lots 2, 3, 4, 5 and 6 in Block 25, Belmont Subdivision to the Town of Midland, Midland Cоunty, Texas, should be reversed and judgment here rendered that as against B. H. Grube, appellee Intervenors take nothing, and the judgment decreeing foreclosure upon the above described lots should be set aside ■and held for naught; and that in all other respects the judgment should be affirmed.
It is so ordered. Reformed and affirmed.