113 F. 218 | 2d Cir. | 1902
This cause came here upon appeal from a judgment of the circuit court, Southern district of New York, entered upon a verdict in favor of the defendant in error, which was plaintiff below. The action was brought upon a contract to recover for machinery manufactured by plaintiff, and for extra work, labor, and materials outside of said contract. The defendant set up by counterclaim charges for materials furnished, and for expenses and damages by reason of imperfect work and failure to complete the contract within the time specified. The proposal contained in the following letter was accepted by defendant, and states the contract between the parties;
“New York, Feb. loth, 1803.
“Arthur P. Dodge, Esq., 27 William Street, New York City — Dear Sir: We will build for you one of your class C, double truck, 8"xl2" cylinder, motor cars, according to your plans, patterns, and specifications.
“I. We will furnish all labor and material, excepting as provided in paragraph II.' below, at actual cost to us, plus 35% f;,r superintendence, fixed charges, etc.; material furnished by us to be weighed as received by us from the manufacturers, or from our own forge and foundry. We will furnish you promptly with time cards showing the amount of work done by our workmen as Hie work progresses on the motor, as well as bills for all materials purchased by us, together with the weight of the same.
“II. We would not make the ear brdy or furnishings, but would prefer to have you furnish material and build the same, to be delivered to us at our factory; and we will do whatever work is necessary to be done in connection with the completion of the motor ear. You are at liberty to furnish the steel castings and condenser.
“ill. We will agree to -push the work of constructing the motor as fast as consistent with the furnishing of satisfactory materials and workmanship, and we estimate that we can complete it within two months from receipt of the necessary drawings and patterns. We will agree to complete the construction of the motor in accordance with drawings, specifications, and patterns, materials or parts, furnished us by you, within that time, provided no changes are made therein by you, or per your instructions, and that we are not delayed by failure on your part to furnish same to us as required for getting out the work, and also provided we are not delayed by strikes of workmen, or other causes beyond our control.
“IV. The payment for this motor to be as follows: On the above basis, and the total amount not to exceed four thousand (4,000) dollars for the completed motor, exclusive of the car body and furnishings; the same to be paid in full within three months after the acceptance of the completed motor; such acceptance to be based on your approval of materials and workmanship, as per drawings, specifications, and patterns, parts or materials, furnished by you, and to bo given by you to us within ten days after the completion of the motor by us in accordance with such drawings, patterns, specifications, parts, and materials, and before the motor is removed from our works; this payment to be guarantied to us by the Metropolitan Trust Company of the City of New York, or otherwise satisfactorily secured.
“V. In view of the special nature of the work, we should require, that you have an inspector at our works during the construction of the motor, who shall be competent and authorized by you to pass upon all materials and workmanship as the work progresses, and ho shall have the right to reject all such as shall not be in accordance with this agreement.
“Awaiting your early acceptance, we are,
“Very truly yours, The Dickson Mfg. Co.
"Per —-—.”
In accordance with the provisions of this contract, the defendant sent Hodges, one of its employés, to plaintiff’s factory; and he
“New York, May 31st, 1898.
“Arthur P. Dodge, Esq., Lords Court Building, New York — Dear Sir: Your representative at Scranton refused to-day to accept the motor car which we have built for you, and also said he was not in a position to approve the bills therefor. Of course, as it is a part of our agreement that we have such acceptance and approval before shipment of car from our works, we are holding it.
“Yours truly, The Dickson Mfg. Co.,
“Per II. L Davis.”
Plaintiff replied as follows:
"June 1st, 1898.
“Dickson Mfg. Co., 40 Wall Street, New York City — Gentlemen: Your letter of 31st ult. just received, and I note that you say that my ‘representative at Scranton refused to-day to accept the motor car which we have built for you,’ ete. Mr. Hodges, my representative, writes me this morning that you refused to allow the car to be shipped after it was loaded, unless he would not only accept and approve all of the work and material, but would approve of your bill for the same, which account has not yet been presented or even made out, and which could not be approved, certainly, before presentation. There is nothing in our contract that requires the approval of your bills before you deliver to us the result of your work and material. All that we are required to do is to accept the work and material when ready to be delivered to me. Hence I hereby accept and approve of all the material and work as placed upon the car ready for shipment to Wilmington to-day, in accordance with our contract of February 15, 189S, and now request that you telegraph to have the car shipped to Wilmington at once. Whenever you have your account ready, together with the time cards, &e., I shall be very glad to receive the same, and will then consider the correctness- of the account. Awaiting your prompt reply, I am,
“Very truly yours, Arthur P. Dodge.”
The motor car was then shipped to Wilmington in accordance with said request.
Plaintiff further showed that it had supplied extra work and materials upon the order of said Hodges, and that on June 2d it rendered to defendant a bill for $4,000 for said motor, and for $936.59 for extra work.
On August 12, 1898, defendant sent a letter and statement to plaintiff, the material portions of which are as follows:
“August 12, 1898.
“Dickson Mfg. Co., 40 Wall Street, City — Gentlemen: The total for the ‘completed motor,’ exclusive of the car body and furnishings, it is agreed*221 by the terms of your contract of February 15th, 1898, with me, is not to exceed §4,000. From this §4,000 should he deducted such bills as I have paid, which make up the cost of the ‘completed motor.’ * * » Inclosed 2nd a statement showing what I make the balance due you to this date, viz., §1,377.31.
“Yours very truly, Arthur P. Dodge.”
“Statement of Cost of Gar No. 5.
1898.
June 30. See Pusey & .Tones Co.’s hill for labor
and materials at Jackson & Sharp Co............§ 64 67
July 7. do do ............ 25 42
July 20. do do ............ 17 68
§ 107 77
July 26. See Jackson & Sharp’s bill extra work... 1,637 66
Mar. 28. Paid Abendroth & Boot Mfg. Co. for con* denser ........................................ 491 31
Mar. 25. Paid Penn Steel Casting & Machry. Co. fcr castings used in the car..................... 207 60
April 9. Paid Crosby Steam Gauge & Valve Co.... 8 00
July 5. Paid O. C. Jerome Packing Co. for packing ........................................... 40 00
Dr. Dickson Mfg. Co............................. §2,490 34
Or. Dickson Mfg. Co. as per contract...................... §4,000 00
Or. Dickson Mfg. Go. as per bill of extras April 1, 1898.,.... 388 68
§4,388 68
Less Dr. Dickson Mfg. Co. as above..... 2,490 34
§1,898 84
Less additional charges:
Labor and attendance in moving motor from Babylon, L. I., to Chesterfield, Mich...........§111 54
Say same amount of cost in returning motor to Babylon, L. I................................. Ill 54
Freight on motor from Babylon, L. I., to Chesterfield, Mich................................... 141 80
Say same amount for returning motor........... 141 90
Paid boiler inspector at Detroit, Mich........... 5 00
June 13. Additional charge for insurance on motor and boiler at New Baltimore, Mich......... 9 15 521 03
Amount due Dickson Mfg. Co............... §1,377 31”
The court charged the jury that the plaintiff, on this evidence, had made out a prima facie case for $4,388.68; that defendant, by its inspection and acceptance, had waived its right to object to defective materials and workmanship, and to charge for putting said motor car in condition in which it would work properly.
The defendant relies upon the rule that in a contract by a manufacturer there is an implied warranty of good materials and skillful workmanship, and, where the manufacturer is notified that the article is to be manufactured for a particular purpose, there is an implied warranty against latent defects arising in the process of manufacture which would render it unfit for the purpose stated. But defendant has failed to note the exceptions that, where a known and described article is thus ordered for a particular pur
The defendant contended that under the written contract, Exhibit A, it was entitled to demand a final test of the completed motor at plaintiff’s works, in order to determine its fitness for the purpose desired, and that inasmuch as it was incomplete when it was shipped to Wilmington, Del., the defendant had the right to make said final test at Wilmington; that the acceptance of the motor at plaintiff’s works was only an acceptance of such material and workmanship as was there capable of determination, but that there was an implied warranty against latent defects which survived such acceptance; and that the question of compliance with said warranty could only be determined by such final test at Wilmington. In support of this contention, the defendant, upon the trial, offered evidence of the character of the tests made at Scranton, for the purpose of showing that such tests were necessarily preliminary and incomplete, because, inter alia, the parts necessary to a complete motor car had not been assembled; and of the character of the tests made at Wilmington, in order to show that the alleged defects were such as not to be discoverable until the bodjr of the car was mounted upon and connected with said machinery. The court excluded this evidence on the ground that defendant, by its letter of June 1st, had expressly accepted the motor in its then condition at Scranton, and had thereby waived its right to insist on a further test. On May 10th the defendant had written to the plaintiff as follows:
“X believe that, by the terms of our contract, we were to inspect and accept at your 'works in Scranton the work you are constructing for us, when you say it is ready therefor, if found correct. By reason of the great delays, and for other reasons, it seems to be desirable that we go to the additional expense of shipping such work, namely, the trucks, boilers, condensers, etc., from Scranton to the Jackson & Sharp Co., at Wilmington, Delaware, for erection. I wish to ask if you will be willing to so modify our contract as to permit of such testing and acceptance by us after they shall reach the shop? of Messrs. Jackson & Sharp, instead of at your own works, as previously arranged.”
“Of course, as it is a part of our agreement that we have such acceptance and approval before shipment of car from our works, we are holding it.”
Under the original agreement, defendant was to furnish his special inspector to pass upon all material and workmanship, with power to reject such as should not conform to said agreement; to build the car body and furnishings, and deliver the same to plaintiff at its factory, the plaintiff doing there whatsoever work might be necessary for the completion of the motor car; to pay after acceptance of the motor thus completed, such acceptance to be based on his approval of materials, workmanship, etc., according to the drawings, etc., furnished by defendant, and to be signified before the motor should be removed from plaintiff’s works. Even if ’defendant, under his original agreement, might have claimed a further test, such right was waived by the subsequent acts and correspondence. Three months and a half after the making of the agreement, defendant, while claiming that plaintiff had failed to complete the contract within the time limited, and after his inspector had complained that there were serious visible defects in the construction of the motor, and after having learned from plaintiff that said inspector had refused to accept said motor, and after having failed to furnish the car body as agreed, the presence of which defendant admits was necessary to finally test the fitness of the motor, writes to plaintiff in response to its refusal to ship before acceptance as follows :
“All that we are required to do is to accept the work and material when ready to be delivered to me. Hence I hereby accept and approve of all the material and work as placed upon the car ready for shipment to Wilmington.”
It cannot be said that plaintiff impliedly consented to a further test at some other factory, or that the alleged implied guaranty survived and was imported into the new contract. On the contrary, the correspondence shows that both parties understood the limitations of the original contract, and the effect of such modification. The defendant had the right to refuse to accept and approve said motor, provided it was not completed within the time limited, or because of defective workmanship and material. He might have had the right, if he had furnished the car body, to insist upon a final test of the com - pleted motor car. He did none of these things, but elected to waive his rights, under conditions known to him, and to accept and approve what his inspector had refused to accept and approve, in order that he (the defendant) might obtain possession of the motor. There was no error in the exclusion of said evidence.
The defendant further contends that the court “erred in holding that there was sufficient proof of the value in the theory of the account stated.” The facts in regard to this exception are as follows: The agreement provided that the total amount of payment for the motor should not exceed $4,000. The plaintiff claimed that the cost of the motor to it, pins the agreed manufacturer’s profit, exceeded
The judgment is affirmed.
