Anthony Costrini and others (collectively referred to as Costrini) 1 appeal from the trial court’s grant of summary judgment to defendants Hansen Architects, P.C. and J. Paul Hansen (collectively referred to as Hansen) on claims for breach of contract, negligence, and fraud arising out of the construction of an office building. Costrini contends that the trial court erred by finding that the claim for breach of contract was time-barred and that Hansen’s alleged fraud did not toll the statute of limitation. For the reasons set forth below, we affirm.
Summary judgment is proper when there is no genuine issue of material fact and the movant is entitled to judgment as a matter of law. OCGA § 9-11-56 (c). A de novo standard of review applies to an appeal from a grant of summary judgment, and we view the evidence, and all rеasonable conclusions and inferences drawn from it, in the light most favorable to the nonmovant.
Brown v. Ohio Cas. Ins. Co. 2
Viewed in this light, the record shows that Costrini hired Hansen to design and supervise improvements to an office building located in Savannah. In late 1988, Costrini complained to Hansen about water problems with the structure, but Hansen insisted that the problems were not attributable to him. In March 1994, Costrini hired an outside firm to еxamine Hansen’s work, and that firm concluded that the problems were attributable to Hansen. Then, on April 1, 1994, Costrini filed suit against Hansen allеging breach of contract, negligence, and fraud. Hansen filed a motion for summary judgment, contending that the claims were time-barred. The trial court granted the motion.
1. Costrini argues that the trial court erred by finding that his breach of contract claim was time-barred bеcause it incorrectly applied the statute of limitation in OCGA § 9-3-30, which provides that “[a]ll actions for trespass upon or damаge to realty shall be brought within four years after the right of action.” Costrini contends that this claim is governed by OCGA § 9-3-24, which provides: “All actions uрon simple contracts in writing shall be brought within six years after the same become due and payable. However, this Code *137 section shall not apply to actions for the breach of contracts for the sale of goods.” OCGA § 9-3-24. Although we agree that OCGA § 9-3-24 apрlies, we nonetheless conclude that the claim is time-barred.
The trial court mistakenly relied upon Kemp v. Bell-View, Inc. 3 in concluding that the four-year limitation in OCGA § 9-3-30 applied because the breach of contract concerned damage to real property. In Kemp, the plaintiffs sued the manufacturer/sellеr of windows for property damage to their home. Ruling that a four-year limitation period applied to the claim, the cоurt stated:
An action for damage to realty must be brought within four years after the right of action accrues. OCGA § 9-3-30. Whether count one is construed as a claim for breach of contract, breach of implied warranty, negligence, or strict liability, it is governed by a fоur-year limitation for filing suit. See OCGA § 11-2-725.
Kemp, supra. The property damage claim in Kemp was subject to a four-year limitation period even if it was actually a breach of contract claim because it related to the sale of goods under OCGA § 11-2-725. Thus, Kemp does not hold that breach of contract claims involving prоperty damage are governed by OCGA § 9-3-30. Indeed, this court has recently ruled that “the four-year statute of limitation in OCGA § 9-3-30 applies only to tort actions for damage to property. Actions arising out of contract do not fall within OCGA § 9-3-30’s purview.” Mitchell v. Jones 4
Applying OCGA § 9-3-24, Costrini’s claim is time-barred because the construction was substantially completed more than six years before Costrini filed suit in April 1994. “The period of limitation on a construction contract commences on the date the work was substantially complete.” Fort Oglethorpe Assoc. II v. Hails Constr. Co. &c.; 5 Space Leasing Assoc. v. Atlantic Bldg. Systems. 6
Hansen, the movant, produced a signed certificate of substantial completion as of December 14, 1987, and a certificate of ocсupancy for the building issued on December 16, 1987. Hansen identified and referenced the affidavit of substantial completion and the certificate of occupancy in his affidavit and attached them to it as exhibits.
Costrini argues that the date of substantial completion was much later, contending that he did not accept the building until April *138 1988 and that final payment on the building did not occur until December 1988. Thus, the contract did not become “due and payable” until that time. However, pretermitting whether the statute of limitation would run from thаt point if such facts were true, the record shows no competent evidence 7 for this Court to consider in support of Costrini’s contention. Because Costrini failed to rebut Hansen’s evidence showing that the date of substantial completion was more thаn six years prior to the filing of this suit, the grant of summary judgment to Hansen was proper. “A grant of summary judgment must be affirmed if it is right for any reason.” (Punctuatiоn omitted.) Nairon v. Land,. 8
2. Costrini also contends that the trial court erred by granting summary judgment to Hansen because the statute of limitation was tolled by Hansen’s fraud. Costrini argues that Hansen deterred him from bringing the suit because Hansen denied liability and told him that the water problems were not rеlated to the design and sequence of construction of the building, but were caused by others. Costrini’s argument fails because Hansen’s аctions do not constitute fraud within the meaning of OCGA § 9-3-96.
Section 9-3-96 provides: “If the defendant or those under whom he claims are guilty of a frаud by which the plaintiff has been debarred or deterred from bringing an action, the period of limitation shall run only from the time of the plaintiff’s discovery of the fraud.” However,
the fraud in question is not that which gives a cause of action, but that which conceals a cаuse of action. To constitute concealment of a cause of action so as to prevent the running of limitations, sоme trick or artifice must be employed to prevent inquiry or elude investigation, or to mislead and hinder the party who has the cаuse of action from obtaining information, and the acts relied on must be of an affirmative character and fraudulent.
(Punctuation omitted.) Turner v. Butler. 9
The reсord contains no evidence that Hansen affirmatively concealed any allegedly defective construction or thаt he hindered or prevented Costrini from discovering any alleged defect. See Mitchell v. Jones, supra. Indeed, in March 1994, almost six years after discov *139 ering the water problems, Costrini first hired an outside firm tо examine Hansen’s work. Costrini was aware of the water problems and could have hired an outside firm earlier.
Judgment affirmed.
Brown v. Ohio Cas. Ins. Co.,
Notes
Appellants are Anthony M. Costrini, J. Allen Meadows III, and David G. Smith, individually and d/b/a Costrini, Meadows & Smith Building Partnership.
Kemp v. Bell-View, Inc.,
Mitchell v. Jones,
Fort Oglethorpe Assoc. II v. Hails Constr. Co. &c.,
Space Leasing Assoc. v. Atlantic Bldg. Systems,
Although Costrini attached certain documents to his affidavit, he did not reference them in his affidavit or otherwise authenticate them. See
Davis v. First Healthcare Corp.,
Nairon v. Land,
Turner v. Butler,