189 F. 576 | 6th Cir. | 1911
The plaintiff in error (hereinafter called the defendant) had a contract with the board of education of Ann Arbor, Mich., for the construction of a high school and library building, to be completed by August 15, 1906. The defendants in error (hereinafter called the plaintiffs) were unsuccessful bidders for this contract, and after its award to defendant entered into contract with him, through an offer in writing (accepted by the defendant) in the following language:
‘Ann Arbor, Mieb., July 8, 1905.
“Mr. E. M. Campfield, General Contractor, High. School and Library, Ann' Arbor, Michigan — Dear Sir: We will furnish yon all the timber as below, sizes and prices hereafter named and specified free on board cars Ann Arbor, Mich.. Ann Arbor Ry. delivery, for the High School and Library Building. Quality to be as per specifications for said building, all as per sizes and specifications, which you are to furnish us. And will do all in our power to get a quick delivery, especially the first floor tier of floor joist. (The following prices are net.)”
A schedule of prices and sizes followed. Plaintiff sued for the unpaid price of lumber furnished under this contract. The defendant set up a counterclaim for breach of contract, in failing to deliver lumber as demanded. On the first trial plaintiffs recovered, defendant’s counterclaim being rejected, under a construction adopted by the Circuit Court, that the contract was unilateral. This court reversed the judgment of the Circuit Court and awarded a new trial, construing the contract as binding the plaintiffs to furnish and the defendant to buy thereunder all of the timber required for the building. Campfield v. Sauer, 164 Fed. 833, 91 C. C. A. 304. Upon a new trial plaintiffs have again recovered. The important facts, so far as they need now be set out, are these:
During July, 1905, defendant sent plaintiffs four orders under the contract, amounting to $8,768.43. Defendant paid thereon $7,211.33
In that case there was a contract for the sale of lumber on credit. The seller refused to deliver on credit, offering, however, to deliver for cash at a reduced price, the reduction more than equalling the interest for the term of credit. The buyer did not allege inability to pay cash, but asserted that he was unable to obtain the lumber from others than the seller at the place of delivery or other available market. It was held that the buyer could not recover damages on the ground that he had bought for resale at another place at an advance over the contract price and cost of transportation, for the reason that plaintiff had received from defendant an unconditional offer to furnish the lumber at a reduced price. No question was made of the ability and readiness of the defendant to so furnish. In that case Judge (now Mr. Justice) Lurlon, speaking for this court, said:
“The offer after the breach by defendants to sell the lumber necessary to complete the contract was not coupled with any condition operating as an abandonment of the contract, nor as a waiver of any right of action for damages for the breach.”
In the case before us plaintiffs’ offer to furnish the lumber was not unconditional. Oil the contrary, the statement was:
“We are perfectly willing to furnish the lumber, provided only ybu will stand the difference caused by the increase in price since our original agreement and as per your verbal agreement above mentioned.”
It is clear that had defendant accepted this offer he would have abandoned all claim for damages for the difference in price so paid. He was under no obligation to make such waiver for the sake of saving plaintiffs from liability for the damages which might result from delay through purchasing elsewhere. Coulter v. B. F. Thompson Lumber Co. (Sixth Circuit) 142 Fed. 706, 74 C. C. A. 38; Hirsch v. Georgia Iron &. Coal Co. (Sixth Circuit) 169 Fed. 578, 95 C. C. A. 76. In the latter case Judge Lurton, speaking of the rule recognized in Lawrence v. Porter, that one who has been damaged by the breach oí a contract must do nothing to aggravate his injuries, and all that he reasonably can to mitigate the loss, said:
"The duty imposed by the equitable rule referred to must be held within reasonable bounds. It Is a rule which has never been regarded as requiring one to yield to a wrongful demand that he may thereby save the wrongdoer from the legal consequences of his own error*.”
Nor does it indisputably appear that, after plaintiffs’ refusal in October to furnish the lumber, defendant could have obtained lumber of the required dimensions in time to have prevented the alleged delay in
Plaintiffs earnestly contend that the delay in the completion of the building was occasioned solely by defendant’s fault in not sooner furnishing lists of the kinds and sizes of timber needed, .and there was testimony tending to support this contention. As said by this court upon the former review, it “devolved upon Campfield to furnish Sauer & Co. from time to time lists of the quality and sizes needed.” The trial court instructed the jury that it was the duty of the defendant “from time to time as the building progressed to order from the plaintiffs the timber of the agreed sizes necessary to be used in the construction of the buildings; and it is for the jury to determine whether the defendant Campfield in any manner or form broke the contract in this respect.” On July 26, 1905, plaintiffs, in acknowledging the receipt of the order, wrote, “Kindly send the balance of stock required at once,” evidently referring to lists of quality and sizes needed. Defendant, however, sent no orders between July 26th and October 18th. Defendant testified that the work 'was suspended about 60 days “between January and spring time,” and that the occasion of the delay was lack of floor joists and roofing timbers. This was heavy stuff. Defendant testified that a portion of this material was obtained by him in Chicago, by having it ripped out of larger stuff, and that other portions he had to have sawed in the south, and that “in* the course of business after we placed the order for timber in the south, with the Holton people for instance, it was some 4 or 5 months before we could get it.” One of the plaintiffs testified that plaintiffs did not
The record raised, in our opinion, questions of fact under all the testimony, including the time required or taken for the delivery of lumber under the July orders, the testimony as to the time required to get out special sizes, and such knowledge as each party had of the general requirements of the building specifications, whether the defendant unreasonably delayed furnishing the lists of dimensions- required, and whether plaintiffs could reasonably have procured the same by due diligence, after orders therefor were furnished by defendant, in time to have prevented the alleged delay in whole or in pari. But these questions of fact we cannot pass upon without assuming the province of the jury. In view of the ground upon which the claim for special damages by reason of delay in the completion of the building was denied, the question of the sufficiency of the evidence offered to support such claim is not properly before us.
To what extent the alleged failure to make prompt deliveries under the July orders contributed to the delay in completing the building is not very dear. And as the case must be tried again on account of the erroneous exclusion of the question of damages for delay occasioned by the October refusal, what we have already said as to liabilities
2. Defendant claimed there were shortages in amount and defects in quality of the lumber furnished under the July orders amounting to $345.97. The jury, as we construe the charge, were instructed that defendant was entitled to credit fo.r such shortages and defects so far as shown. They were instructed, however, with respect to the creation of a breach of contract thereby “in the sense that a claim for damages 'could be based thereon,” that (1) it must'appear “that proper and reasonable notice of such shortages in quantity and defects in quality was .'given by the defendant to the plaintiffs and that the plaintiffs refused ■or failed, within a reasonable time subsequent to such notice, to supply such shortages in amount or to repair such defects in quality;” (2) that such notice of shortages and defects in order to have been “proper and reasonable under the circumstances, must have been given 'by the defendant to the plaintiffs in a manner conformable to the custom of the lumber trade so far as said custom applies to the contract” in question; and (3) that if notices of shortages and defects were “not given in proper time or with sufficient definiteness to enable plaintiffs to supply those deficiencies under their contract with their vendors and manufacturers” no proper or reasonable notice was given. Dater, however, the instruction was given that:
“If the jury shall find from the evidence that the plaintiffs failed to fill ■completely all the orders for the timber in question which defendant Camp-field made in the month of July, 1905, and that there was actually lacking timber of the value of $345.97 or any less amount, then the plaintiffs broke their contract and defendant Campfield is entitled to recover damages for such breach.”
It would seem that the later instruction neutralized the former instructions to which we have referred, and as the judgment is to be reversed, it is perhaps unnecessary to now pass upon the correctness of the earlier instructions. As, however, the question may arise upon a new trial, it is proper to say that we see no error in the general proposition contained in the first instruction; that the second instruction should not have been given, for the reason that the testimony upon which it is based relates merely to “a usage of the lumber trade” which is not shown either to have been general or known to defendant; and that the cori-ectness of the third instruction depends upon the defendant’s knowledge of the plaintiffs’ contracts with their vendors.
3. Several other alleged errors are discussed by counsel, but as these questions are not controlling and not very likely to arise upon a new trial, we do not deem it our duty to discuss them.
The judgment of the Circuit Court will be reversed and a new trial ordered.