386 N.W.2d 599 | Mich. Ct. App. | 1986
BENNINGTON TOWNSHIP
v.
MAPLE RIVER INTER-COUNTY DRAIN BOARD
Michigan Court of Appeals.
Shulaw & Bowne, P.C. (by Lynn D. Bowne), for plaintiff.
W.J. Drillock, for defendants.
Before: BRONSON, P.J., and R.B. BURNS and R.C. KAUFMAN,[*] JJ.
R.B. BURNS, J.
Plaintiff appeals from the trial court's grant of summary judgment in favor of defendants pursuant to GCR 1963, 117.2(3), now MCR 2.116(C)(10). Plaintiff appeals and we reverse.
Plaintiff's complaint alleges numerous violations of the Drain Code of 1956, MCL 280.1 et seq.; MSA 11.1001 et seq., in connection with a proposed drain project. In addition, plaintiff alleges that defendants abused their discretion in not taking any action in the 14 years since the project was approved other than spending over $1,000,000. Ultimately, plaintiff seeks the abandonment of the entire drain project.
The Maple River goes through Shiawassee, Clinton, and Gratiot counties, with its headwaters in Shiawassee County. A county drain was established along the river in 1903 in Gratiot County and an intercounty drain was established along the river in 1905 between Shiawassee and Clinton counties. Sometime in late 1967 or early 1968, petitions were filed with the drain commissioners of the three counties requesting that in intercounty drain be established in the three counties along the river. The exact date of the filing of these petitions is unknown as the dates were never recorded in any of the three counties. After defendant *583 Drain Board, then newly-formed and consisting of the drain commissioners from the three counties, found the proposed project to be practical, a First Order of Determination was entered on June 26, 1968, apportioning the cost of the drain project among the three counties.
After further consideration of the matter, defendants decided to apply to the Soil Conservation Service for assistance from the federal government on the drain project. A Watershed Plan Agreement was reached on August 15, 1969, with the service. Under the agreement, the engineering would be done by the Army Corps of Engineers, with environmental impact statements to be obtained in the near future. It was subsequently determined that, for the purposes of obtaining federal funds, a wildlife area would be created, so defendants agreed with the Michigan Department of Natural Resources to participate in the department's wetlands project. Because money had to be obtained for the acquisition of land and other purposes, in 1973 an application was made to the Farmer's Home Administration to borrow over $1,500,000 for the purpose of obtaining land for dikes, water retention areas, and flood plains. In 1977, defendants amended the First Order of Determination in order to add more lands to the intercounty drain district, though the apportionment of costs between the counties remained the same.
In 1981, approximately 13 years after the Maple River Drain project was originally proposed, work had not yet begun on the drain, though it appeared that the cost of the project had escalated from the initial estimate of $6,000,000 to over $30,000,000. Because of the increase in costs, defendants decided to abandon the federal project and attempt to build the drain, in a scaled-down *584 version, with local funds only. In March of 1984, defendants changed the scope of the drain project again, planning to do less work in Shiawassee County. In addition, a resolution was proposed and passed increasing Shiawassee County's contribution from 25% to 35%, Clinton County's from 10% to 20%, and decreasing Gratiot County's from 65% to 45%. As of January 1, 1984, defendants have incurred liabilities of over $1,000,000, with work still not begun on the drain project.
Summary judgment was granted on several of plaintiff's claims on the grounds that there was no genuine issue of material fact and defendants were entitled to judgment as a matter of law. GCR 1963, 117.2(3), now MCR 2.116(C)(10). In order to prevail on such grounds, the movant must show that no future development of the evidence could justify a judgment in the opposing party's favor:
"A motion for summary judgment premised upon the ground that there is no genuine issue as to any material fact, GCR 1963, 117.2(3), requires the trial court to review the entire record to determine whether the non-moving party has discovered facts to support the claim or defense. The trial court is obligated to look beyond the pleadings and consider affidavits, depositions, and interrogatories. Based upon the entire record, the trial court must give the benefit of any reasonable doubt to the opposing party in determining whether there is a genuine issue as to a material fact. Rizzo v Kretschmer, 389 Mich. 363, 371-372; 207 NW2d 316 (1973). Before judgment may be granted, the court must be satisfied that it is impossible for the claim asserted to be supported by evidence at trial. Partrich v Muscat, 84 Mich. App. 724; 270 NW2d 506 (1978); Fry v Ionia Sentinel-Standard, 101 Mich. App. 725; 300 NW2d 687 (1980)." Huff v Ford Motor Co, 127 Mich. App. 287, 293; 338 NW2d 387 (1983).
In ruling on such a motion, the trial court should *585 be liberal in finding a genuine issue of material fact. Rizzo v Kretschmer, 389 Mich. 363; 207 NW2d 316 (1973). We address each of plaintiff's theories separately.
I
Plaintiff first argues that there was a genuine issue of material fact concerning plaintiff's claim that defendants failed to satisfy the contract letting and notice provisions of the Drain Code. Plaintiff alleges that two different provisions of the statute were unsatisfied.
First, plaintiff alleges that defendants failed to comply with the requirement that contracts be let within five years after the filing of the petitions to establish the drain. Prior to April 30, 1973, § 126 of the Drain Code[1] provided as follows:
"At the time and place fixed in said notice, or at an adjourned date, the drainage board shall receive bids and let contracts for the construction of the drain in the manner prescribed in chapter 9, being sections 221 to 223, inclusive, of this act. If no contract shall be let within 5 years after the date of filing the petition to locate, establish and construct the drain, the petition shall be deemed abandoned and no further action shall be taken to construct said drain unless a new petition shall be filed: Provided, That time during which any litigation shall be pending to contest the validity of such proceedings shall not be counted as a part of such 5-year period." 1956 PA 40, § 126.
However, 1973 PA 16 (effective April 30, 1973), amended § 126 to provide that, if no contracts are let within the five year period, "the drainage board may determine that the petition shall be deemed abandoned". (Emphasis added.) Thus, *586 abandonment is no longer mandatory. The amendment further provided that the "provisions of this section shall apply to all petitions which are in full force and effect on the date of January 1, 1973, or thereafter". Accordingly, it must be determined whether the petitions in the instant case were "in full force and effect" on January 1, 1973. If so, there was no automatic abandonment of the project.
If the petitions were filed prior to January 1, 1968, and no contracts were let, the pre-1973 version of the statute would have deemed the project abandoned five years after the filing of the petitions. That is, if the petitions were filed in late 1967, as alleged by plaintiff, then in late 1972 the project would have been deemed abandoned for failure to let contracts. Accordingly, the petitions for the instant drain project would not have been "in full force and effect" as of January 1, 1973, and therefore would not be saved by the 1973 amendment.
The trial court and defendants contend that, in the absence of any proof, it should be assumed that the petitions were filed on April 30, 1968, as stated in the Order of Practicableness. Plaintiff alleges a time period falling somewhere between September 12, 1967, and February 5, 1968. The basis for this is that, under the Drain Code, 106 signatures on the petitions to establish the project were required. MCL 280.121; MSA 11.1121.[2] As of November 22, 1967, circulators of petitions containing 164 signatures of freeholders had filed affidavits that the petitions had been properly passed out and signed. At the latest, claims plaintiff, the petitions were filed on February 5, 1968, *587 when the drain commissioners of the three affected counties certified that all petitions were checked and all signatures verified.[3] Thus, depending on the exact date, the previous § 126 may apply.
Upon an examination of the available evidence, it is clear that there was still a genuine issue of material fact as to when the drain petitions were filed. If anything, the arguments of the parties show that there is a serious disagreement over a critical fact, with both sides having support for their positions. Therefore, we conclude that the trial court erred in granting summary judgment on this issue. The matter will have to proceed to trial to determine whether the petitions were filed prior to January 1, 1968.
Plaintiff's second contention under this issue is that § 122 of the Drain Code,[4] which requires county drain commissioners within 20 days of receiving a petition concerning an intercounty drain to notify the other affected counties' drain commissioners and the director of the Department of Agriculture of the filing, was not complied with. The trial court, in concluding that the notice requirement had been complied with, based that conclusion on the premise that the petitions had been filed on April 30, 1968, and that notice was given on May 3, 1968. Reversal on this issue is also required since we have concluded that there is a genuine issue of material fact on the question of the date of filing of the petitions.[5]
*588 Before concluding this issue, we wish to briefly consider defendants' defense of laches, based on plaintiff's 14-year delay in raising its objections. Laches is an equitable defense which demands a passage of time combined with prejudice to the defendant:
"Laches is an affirmative defense which depends not merely upon the lapse of time but principally on the requisite of intervening circumstances which would render inequitable any grant of relief to the dilatory plaintiff. Lewis v Poel, 376 Mich. 167, 169; 136 NW2d 7 (1965), Root v Republic Ins Co, 82 Mich. App. 446; 266 NW2d 842 (1978). For one to successfully assert the defense of laches, it must be shown that there was a passage of time combined with some prejudice to the party asserting the defense of laches. Head v Benjamin Rich Realty Co, 55 Mich. App. 348, 356; 222 NW2d 237 (1974), lv den 393 Mich. 792 (1975). See also Wiljamaa v Board of Education of City of Flint, 50 Mich. App. 688, 692; 213 NW2d 830 (1973). Laches is concerned mainly with the question of the inequity of permitting a claim to be enforced and depends on whether the plaintiff has been wanting in due diligence. Sloan v Silberstein, 2 Mich. App. 660, 676; 141 NW2d 332 (1966)." In re Crawford Estate, 115 Mich. App. 19, 25-26; 320 NW2d 276 (1982).
While defendants' argument that plaintiff's almost 14-year delay in bringing suit is inequitable seems at first blush to have merit, there are several reasons why it is not convincing. First, as a rule the doctrine of laches will not be persuasive where the underlying claim is a lack of jurisdiction over a drain project, which is the case here with plaintiff's §§ 122 and 126 claims. Quarderer v Shiawassee County Drain Comm'r, 82 Mich. App. 692, 697-698; 267 NW2d 151 (1978). Second, there *589 does not seem to be a lack of due diligence on the part of plaintiff, which this doctrine is designed to "punish". While the code violations at issue did arise some ten years before suit was filed, it seems that the plaintiff was willing to wait and see if defendants would eventually act on a drain project which at first appeared beneficial to all concerned. It was only after approximately $1,000,000 was spent on a project that had not yet been begun and after the 1981 decision to totally finance this drain project with local funds, that plaintiff realized that defendants would, in plaintiff's opinion, never properly oversee this project. This prompted the filing of suit by plaintiff one year later. Given this pattern of action, laches would not be appropriate. See Rofe v Robinson (On Second Remand), 126 Mich. App. 151; 336 NW2d 778 (1983).
II
Plaintiff next contends that the trial court erred in granting defendants summary judgment on plaintiff's claim that the members of defendant board violated the Drain Code by failing to obtain releases of rights-of-way within 60 days of the First Order of Determination. Section 127 of the Drain Code[6] provides:
"Within 60 days next succeeding the entry of the first order of determination the said commissioners shall within their respective counties endeavor to secure from the owner of each parcel or tract of land which would be traversed or damaged by said proposed drain a release of the right of way and all damages on account thereof." *590 Since no right-of-way releases have yet been sought, this section has not been complied with.[7]
However, we are not convinced that violation of § 127 requires termination of the project. Section 128 of the Drain Code[8] provides for condemnation proceedings to obtain right-of-way releases not obtained in the 60-day period following the first order of determination. We conclude that once the 60-day period has expired, § 128 must be followed to obtain releases. There is no reason to conclude that violation of § 127 requires termination of a drain project. Rather, the Legislature was merely establishing the order in which steps were to be taken and to prevent an immediate resort to condemnation proceedings.
III
Plaintiff next objects to the trial court's grant of summary judgment to defendants on plaintiff's claim that defendants lacked authority to amend the first order of determination with respect to the apportionment of costs of the project between the counties involved. Plaintiff seeks a return to the apportionment of costs contained in the original order. Because of our conclusion to remand for further proceedings on Issue I, we find it unnecessary to consider this issue at this time since, if plaintiff ultimately prevails on that issue, this issue will be rendered moot.
IV
Plaintiff next argues that the trial court erred in *591 granting defendants summary judgment on plaintiff's claim that defendants had abused their discretion in the handling of the drain project. Generally, for an abuse of discretion claim to succeed, something akin to bad faith or fraud must be established. See 2 McQuillin, Municipal Corporations (3d ed), § 10.37, p 834.
Given the available facts, it cannot be said with certainty whether fraud or bad faith on the part of defendants occurred or not. There certainly is circumstantial evidence that could lead to that conclusion, given the great period of time that has elapsed without any progress being made on the drain project and the large amount of liabilities which have been incurred by the drain board, over $1,000,000, on the project so far, with the "recipients" of those funds as of this time not being firmly established. On the other hand, there have been plausible explanations forwarded by defendants for the delays and costs of this project, including delays by the Army Corps of Engineers in providing plans for the project and the need to purchase significant amounts of land for the establishment of a protected wetlands area per the requirements of the federal government if nonlocal funding was to be obtained. Thus, a genuine issue of material fact exists as to plaintiff's claim of abuse of discretion. Therefore, the trial court erred in granting summary judgment.
V
Plaintiff's final argument is that the 1973 amendment to § 126 which retroactively changed the remedy for a violation of § 126, discussed under Issue I, is constitutionally infirm as it impairs contractual obligations or revokes preexisting *592 vested rights. We conclude that it is unnecessary to consider plaintiff's constitutional claims at this time since, as discussed under Issue I, plaintiff may be able to prove on remand that the petitions were filed prior to January 1, 1968. If plaintiff proves that to be the case, the 1973 amendment would be inapplicable in any event and the constitutional issue need not be addressed.
CONCLUSION
The decision of the trial court is reversed in part and affirmed in part and the case is remanded to the trial court for further proceedings consistent with this opinion. Jurisdiction is not retained. No costs, a question of public importance being involved.
NOTES
[*] Circuit judge, sitting on the Court of Appeals by assignment.
[1] MCL 280.126; MSA 11.1126.
[2] That section requires one-half of the freeholders to sign the petitions. In this case, there were 211 freeholders affected, thus requiring 106 signatures on the petitions.
[3] Plaintiff advances the rather logical argument that the signatures could not have been checked and verified without the petitions having been filed.
[4] MCL 280.122; MSA 11.1122.
[5] We specifically do not address the question of the effect of a violation of § 122. Plaintiff argues that a violation of that section deprives defendants of jurisdiction over the drain project. Finding no violation, the trial court did not address the effect of a violation and we offer no opinion at this time.
[6] MCL 280.127; MSA 11.1127.
[7] We have considered and rejected defendants' argument based on the position that this is a maintenance and extension of an existing drain subject to Chapter 8 of the Drain Code, rather than a new drain subject to Chapters 5 and 6. Even if defendants' characterization of the drain project is correct, §§ 121 to 135 are explicitly made applicable to Chapter 8 drains by the provisions of § 192.
[8] MCL 280.128; MSA 11.1128.
