Bellview Cemetery Co. v. Faulks

60 So. 461 | Ala. Ct. App. | 1912

WALKER, J.

The averments of count 3 of the complaint showed the existence of a verbal contract between the plaintiff (the appellee) and the defendant under which the plaintiff was to do certain grading for the defendant at a specified price per cubic yard, the defendant to pay for all grading done on the 15th day of each month after the plaintiff should begin work; that the plaintiff began work under the contract on February 15,1910, and worked continuously up to and including April 15, 1910; and that the defendant failed or *139refused to pay plaintiff for the grading done under the contract to said date. We are of opinion that the count sufficiently shows that the plaintiff did some work under the contract for which the defendant became liable. Its averments fairly import that the plaintiff had done some of the grading called for by the contract. The suggestion that there might have been a more pointed or specific averment to this effect is hypercritical. In showing the existence of a contract, performance under it on the part of the plaintiff, and a breach by the defendant of its obligation to pay, the pleading showed a cause of action in favor of the plaintiff. — Montgomery Mfg. Co. v. Thomas, 20 Ala. 473. It Avas enough, to protect it against the attack made upon it by demurrer, that it showed that the plaintiff Avas entitled to recover something. It cannot be said that the count failed to show the existence of a cause of action because it failed to specify the amount of grading done or to aver that enough had been done to entitle the plaintiff to recover the amount of damages claimed . We are not of opinion that the court was in error in overruling the demurrer to that count.

Besides the special count above referred to, the complaint contained common counts on account and for work and labor done. The defendant filed several pleas setting up claims in recoupment growing out of the alleged failure of the plaintiff to comply with specified stipulations made binding iipon him by the terms of the contract upon which his demand was based. As to some of these special pleas demurrers were sustained, and as to others the demurrers were overruled. Counsel for the appellant do not in argument point out any claim in recoupment Avhich was asserted in either of the pleas which went out on demurrer which could not as Avell have been availed of under some of the pleas *140which, were unsuccessfully demurred to, and we are unable to discover any such claim of the benefit of which the defendant was deprived. It follows that whatever error there may have been in sustaining demurrers to some of these pleas was without injury to the appellant.

The defendant pleaded in recoupment the • existence in the contract upon which the plaintiff’s demand was based of stipulations on his part to complete the grading contracted for by March 1, 1910, and as to the manner of doing the work, and that the defendant had suffered damages in consequence of the plaintiff’s failure to comply with such stipulations. To the pleas to this effect the plaintiff interposed a special replication setting up “that the defendant waived any right that it may have had by reason of the facts alleged in said pleas by recognizing the binding, efficacy of the contract in question after the 1st day of March, 1910, by accepting and using the services of the plaintiff, and making certain payments thereon.” The defendant demurred to this replication upon grounds, among others, suggesting its failure to show such conduct on the part of the defendant as would have the effect of a waiver by it of its asserted claims in recoupment. This demurrer was overruled. This ruling involved the proposition that the defendant, by accepting the benefit of work done by the plaintiff under the contract after the time stipulated for its completion, waived any right it might otherwise have had to recoup the damages sustained by it in consequence of the plaintiff’s failure to comply with his obligations under the contract. A similar proposition was embodied in written charge 8, given at the request of the plaintiff. These rulings cannot be sustained. One for whom another contracts to do specified work within a certain time and in a designated manner does not, by allowing the work to proceed after *141the expiration of tlie time named and accepting the benefit of it, waive his claim to damages for the delay or for the contractor’s failure to comply in other respects with his part of the contract, and, when sued on the contract, may recoup the damages sustained in consequence of such defaults on the part of the plaintiff.— Huntsville Elks Club v. Garrity-Hahn Blg. Co., 175 Ala., 57 South, 750; Woodrow v. Hawving, 105 Ala. 240, 16 South. 720; Gazzam v. Kirby, 8 Port. 253.

One party to a contract does not, by his failure to put an end to it on the other party’s breach of one of its provisions, deprive himself of the benefit of stipulations in his behalf contained in the contract. The result of the rulings above referred to was to deprive the defendant of substantial matters of defense, duly alleged and supported by evidence, upon a ground plainly not entitled to have that effect. For the error in those rulings, the judgment must be reversed.

Reversed and remanded.

midpage