Three related appeals are at issue. In the first appeal, defendant Empire Laboratories, Inc., appeals the district court’s partial grant of judgment as a matter of law in favor of plaintiff CSI Trucking, Inc., on its fraudulent misrepresentation claim, as well as the district court’s entry of judgment, after trial, in favor of CSI on that same claim. In the second appeal, defendant Meridian Aggregates Company appeals the district court’s entry of judg.ment, after trial, in favor of plaintiff Ban-
I.
These appeals, and the underlying case, arise out of the construction of Runway 17L-35R at the Denver International Airport. In the summer of 1991, the City and County of Denver solicited bids for construction of the runway (otherwise known as Project F-111B). Plaintiff Bangert, a Missouri corporation with its principal place of business in St. Louis, was the winning bidder and general contractor on the project. As outlined in its bid, Ban-gert expected assistance from plaintiff CSI, a minority-owned business incorporated in Minnesota, and defendant Kiewit Western Company, a Delaware corporation with offices in Denver. Bangert anticipated that CSI would purchase and haul many of the raw materials required for paving the runway, and that Kiewit would use those raw materials to provide Ban-gert with “batched” concrete necessary for paving the runway. 1
CSI entered into a contract with defendant Meridian Aggregates Company for the rock and sand for the project. Kiewit contacted various companies, including River Cement Company, about cement for the project. To manufacture or “batch” concrete, a “mix-design” or recipe is used which sets forth the specific types and amounts of component materials. In late 1991, Kiewit developed and tested several different mix-designs for possible use on the project. Some of the proposed mix-designs met the strength requirements imposed on the project by the City, but others did not. In particular, the proposed mix-designs utilizing Heartland cement supplied by River did not meet the strength requirements. However, because River was willing to lease space from Kiewit in a railyard located near the construction site, Kiewit continued to explore and test mix-designs utilizing Heartland cement.
At the urging of Kiewit, CSI entered into an agreement with River for the cement for the project. In April 1992, River began shipping Heartland cement. Shortly thereafter, Kiewit, on behalf of CSI, hired defendant Empire, a Colorado corporation with its principal place of business in Fort Collins, to perform additional mix-design testing. In particular, Kiewit asked Empire to determine whether Kiew-it’s proposed mix-designs utilizing the Heartland cement would satisfy the strength requirements imposed on the project by the City. 2
Empire employee Gary Martinson, with the assistance of two subordinates, per
Paving operations began on the project in mid-June 1992 and problems arose almost immediately. As a general matter, the concrete “didn’t work very well” and was difficult for Bangert’s paving personnel to handle. Tr. at 508 (testimony of Henry Bangert). By the third day of paving, Bangert began experiencing problems with the field strength tests on the concrete. Id. These low-strength problems continued off and on throughout the summer of 1992. In mid-July 1992, Bangert discovered that some of the concrete panels were contaminated with “clayballs.” Id. at 515. In September 1992, large quantities of concrete failed to “set up properly,” which in turn led to random cracking of the concrete. Id. at 529. In addition, some of the concrete failed to set at all and remained in a “retarded” state similar to gelatin. Id. at 531.
Bangert investigated and attempted to correct these problems. With respect to the low-strength problem, Bangert experimented with the mix-designs, changing the amounts of cement, fly ash, and admixture in an attempt to increase the concrete’s strength. Bangert concluded there was a relationship between the low-strength problem (and the retardation and cracking problems) and the Heartland cement supplied by River. Bangert further discovered that, adding to the problem, River had shipped three different types of cement to the job site and those three types had been intermingled during the concrete batching process. In the fall of 1992, Bangert, with the approval of the City, switched cement suppliers and discontinued using any cement supplied by River.
Bangert attributed the clayball problem to several potential sources. First, Ban-gert concluded there was clay in the sand stockpile. Second, Bangert concluded that at least some of the rock in the rock stockpile was too dirty to use for batching concrete. Third, Bangert believed that muddy conditions at the batch plant site, as a result of wet weather and a rock-
The concrete problems encountered on the project in the summer of 1992 had significant ramifications. As a result of the low-strength problems, the City deducted $410,000 from its payments to Ban-gert. Id. at 538. In addition, Bangert spent the majority of 1993 replacing and repairing panels of concrete. Id. at 502. In particular, of the 781 panels.of concrete (each measuring 25 feet by 25 feet by 17 inches thick) poured by Bangert between July 21 and September 16, 1992, 332 had to be removed and 206 repaired as a result of the failure of the concrete to properly set. Id. at 583. Bangert also had to replace or repair a number of the panels affected by the clayball problem (which were poured prior to July 21, 1992). Id. at 567-69. In total, Bangert was ordered by the City to replace or repair over 600 panels of defective concrete. -
In 1993, while the project was still ongoing, CSI filed for Chapter 7 bankruptcy protection in Minnesota. CSI sued Ban-gert and Kiewit, and that adversary proceeding was transferred by the bankruptcy court to federal district court in Colorado. Thereafter, Bangert and CSI were realigned as plaintiffs and other defendants, including Empire and Meridian, were added. CSI asserted claims against Empire for fraudulent and negligent misrepresentation based on Empire’s falsification of the mix-design test results. Bangert asserted negligence and breach of express and implied warranty claims against Meridian based on its assertion that Meridian provided contaminated sand' and rock to the project and was responsible (at least in part) for the clayball problem. Meridian asserted two counterclaims against Ban-gert:-a legal claim under the Colorado Public Works Act (CPWA), Colo.Rev.Stat. § ,38-26-105, and an equitable claim for quantum meruit. The basis for both claims was Meridian’s assertion that it had not been paid fully for the materials it provided to the project. A jury awarded CSI compensatory damages of $617,140 and punitive damages in the same amount on its fraud claim against Empire. With respect to Bangert’s negligence and breach of warranty claims against Meridian, the jury found in favor of Bangert and awarded' total damages of $1,252,420. With respect to Meridian’s counterclaim against Bangert under the CPWA, the jury found in favor of Bangert.
After trial, the district court found in favor of Meridian on its counterclaim against .Bangert for quantum meruit and awarded, Meridian $1,346,142 in compensatory damages, plus prejudgment interest. The district court awarded prejudgment interest to Bangert on its successful claims from the first day of trial until the date of judgment. The district court also awarded prejudgment interest to CSI on its successful .claims from January 1, 1994 (the date its claims accrued), to the date of judgment.
II.
Empire’s Appeal (Case No. 00-1024)
Grant of JMOL in favor of CSI — fraud claim
Empire contends the district court erred in granting partial judgment as a matter of law in favor of CSI on its fraudulent misrepresentation claim against Empire. We review de novo a district court’s grant of a motion for judgment as a matter of law, applying the same standard utilized
At the close of all the evidence, CSI moved for judgment as a matter of law on its fraudulent misrepresentation claim against Empire. The district court granted the motion in part, leaving the issue of CSI’s damages for the jury. Tr. at 7109-10. Empire contends the court erred, asserting that it presented sufficient evidence to create a genuine issue of material fact concerning whether it committed fraud. In particular, Empire points to the trial testimony of Martinson (in which Martinson testified that he believed the altered test results more accurately reflected the strength of the mix-designs) and suggests that his testimony, “if believed, would [have] allow[ed] the jury to conclude that he adjusted the test results not for the purpose of misrepresenting the strength of the concrete, but rather to present what he believed to be accurate information.” Empire’s Opening Br. at 36. In other words, Empire argues that the district court improperly focused only on the altered test results, when in fact those altered test results accurately portrayed the strength of the concrete mix-designs.
Empire’s arguments hinge on a misperception of the “material fact” underlying the plaintiffs’ fraud claims. 4 Empire continues to assert on appeal that the “material fact” at issue is not the altered flex-ural strength test results, but rather the professional opinions it offered to CSI regarding the flexural strength of the concrete mix-designs. We agree with the district court, however, that the opposite is true. It was uncontroverfed that Martin-son and his subordinates altered the flex-ural strength test results and reported only the altered test results to CSI and the other entities. Further, it was uncontro-verted that the actual test results would not have been sufficient to meet the project guidelines. Thus, even though Empire attempted to present evidence (gathered after the fact) suggesting that the altered test results accurately portrayed the strength of concrete produced by the proposed mix-designs, the key point is that Empire failed to inform CSI and the other entities of the actual test results. Had Empire done so, and then opined that the actual test results did not accurately portray the strength of the concrete produced by the mix-designs, there would have been no fraud. In other words, there would have been no misrepresentation of any fact, and CSI and the other entities could have determined whether they agreed with Empire’s professional opinion regarding the likelihood of the proposed mix-designs producing concrete of sufficient strength. However, because Empire failed to disclose that it had altered the test results, neither CSI nor any other entity involved in the project knew or had reason to know there might be a problem with the proposed mix-designs.
Failure to' instruct — apportionment of fault
Empire contends the district court erred in refusing to instruct the jury to apportion fault and damages among all entities whose conduct, whether intentional or otherwise, contributed to CSI’s injuries. In particular, Empire points to the conduct of River, which was originally named a defendant in the action but settled with Bangert and CSI prior to trial. According to Empire, River was largely responsible for the concrete problems because, unbeknownst to Bangert and CSI, it shipped multiple types of cement to the job site and those cements were commingled and mixed, in varying amounts, in the batches of concrete used for paving. We review for abuse of discretion a district court’s refusal to give a particular instruction.
Allison v. Bank One-Denver,
Empire’s request for a comparative-fault instruction was based on Colo.Rev.Stat. § 13-21-111.5, entitled “Civil liability cases — pro rata liability of defendants,” which provides:
(1) In an action brought as a result of ... an injury to person or property, no defendant shall be liable for an amount greater than that represented by the degree or percentage of the negligence or fault attributable to such defendant that produced the claimed injury, death, damage, or loss, except as provided in subsection (4) of this section.
Empire also relied heavily on
Harvey v. Farmers Insurance Exchange,
. On appeal, the prevailing insured argued,. in part, that the apportionment of damages between the insurer and the chiropractor on her bad faith claim was incorrect because the chiropractor owed no duty to her and because the insured’s duty of good faith was nondelegable. Before addressing these issues, the court considered “whether apportionment of liability [wa]s proper between defendants, or between defendants and designated non-parties at fault, when one or more [we]re negligent by failing to use reasonable care to prevent the foreseeable harm resulting from the intentional tort of one or more others.”
that § 13-21-111.5(1) wa[s] intended to apportion fault, and therefore liability for damages; between defendants, or between defendants and designated non-parties at fault, where one or more of such persons or entities [we]re negligent by failing to use reasonable care to prevent the foreseeable harm resulting from the intentional tort of one or more of the others.
Id. at 39.
The district court in the instant case reviewed Harvey and concluded it was not controlling. Specifically, the district court emphasized that the discussion of comparative fault in Harvey arose in connection with a negligence claim asserted by the insured against her insurer, and not in the context of an intentional tort claim such as the fraud claims asserted by CSI against Empire. Tr. at 7673. Further, the district court found the Harvey decision unpersuasive:
I don’t choose to buy into that interpretation at this juncture because I think it’s too radical a change in Colorado law for this court to basically go forward on without more authority than one opinion from the Court of Appeals. And I am not at all sure that the opinion from the Court of Appeals is totally persuasive, anyway, because it does apply to a negligence case. It’s broad. The very language you quoted me is extremely broad.
Id. at 7676. Having rejected Empire’s requested instruction, the district court instructed the jury as follows with respect to CSI’s claim for fraud against Empire:
You may not take into account any other claims asserted by CSI against any other defendant, the amount of damages, if any, that you may award to CSI on those claims or the basis for such award. Your award if any, shouldbe for the full amount of compensatory damages awarded to CSI on this claim caused by this defendant without regard to any amounts CSI may recover on other claims against this or other defendants.
Joint App. at 7787-88.
After the verdict, Empire moved for a new trial arguing, in part, that the district court erred in refusing the requested apportionment of fault instruction. Id. at 4300. Empire also asked the district court to certify the apportionment of fault issue to the Colorado Supreme Court. Id. at 4715. The district court rejected Empire’s request for certification, noting that the Colorado Supreme Court had granted cer-tiorari in the Harvey case and was “sure to discuss” the relevant issues “in its opinion on the case.” Id. at 4730. The district court further noted that the decision in Harvey would “be available' for consideration by the court considering the appeal in this case.” Id. Consistent with its ruling on Empire’s motion for certification, the district court also denied Empire’s motion for new trial. Id. at 4764.
While this case was pending on appeal, the Colorado Supreme Court affirmed the decision in
Harvey. See Slack v. Farmers Ins. Exchange,
After reaching its conclusion regarding the meaning of § 13-21-111.5(1), the Colorado Supreme Court rejected the appellant/insured’s argument that, “since [the chiropractor] was an intentional actor, [the insurer] not [the chiropractor] should bear a greater proportion of the loss.” Id. More specifically, the court stated:
In our estimation, the public policy rationale for apportioning the loss commensurate with wrongdoing is even more compelling when an intentional tortfeasor contributes to the injury. Under the terms of the statute, a negligent actor is only responsible for his contribution to an injury, irrespective of whether the other tortfeasor accidentally or purposefully injured the victim. To hold otherwise would lead to the anomaly that a negligent tortfeasor would bear the full risk of the injury if the other tortfeasor purposefully injured the victim, but only his portion of the risk if the other actor were negligent. If any disproportionate responsibilitywere to be assessed, it would more logically fall upon the intentional tortfea-sor-not the negligent one. (Footnote omitted.) Nonetheless, section 13-21-111.5 demonstrates the General Assembly's intent that a tortfeasor should pay only for the portion of the injury he caused.
Id. at 286-87 (emphasis added).
Based upon the decision in Slack, we have little choice but to conclude the district court erred in refusing to instruct the jury to apportion fault among Empire for its false representations and the other entities alleged by Empire to have contributed to CSI's injuries. Although the district court accurately characterized Harvey as a "radical" change in Colorado law, the decision in Slack clearly affirms Harvey's interpretation of Colorado law. Moreover, the opinion in Slack makes clear that Harvey's interpretation of § 13-21-111.5(1) applies to situations such as that presented here where an intentional act precedes the alleged negligent act(s) of others.
The question becomes whether the district court's error prejudiced Empire. Harmless error analysis generally applies in civil cases involving instructional error. See Morrison Knudsen Corp. v. Fireman's Fund Ins. Co.,
CSI contends that any error on the part of the district court in failing to instruct the jury in accordance with § 13-21-111.5(1) was harmless. More specifically, CSI contends there was no need for an apportionment. of fault instruction, as required by § 13-21-111.5(1), "because the jury was expressly instructed to award damages only for injuries that Plaintiffs proved were proximately caused by each Defendant's conduct without regard to any damages Plaintiffs may recover on other claims against that or any other Defendant." Response Br. at 74. CSI furtther notes that the district court utilized separate verdict forms for each claim against each defendant: In CSI's view, the instructions and verdict forms, taken together, "were the functional equivalent of an instruction to apportion liability between Defendants." Id. Additionally, CSI argues that any culpability of River was adequately addressed by the district court's instructions on intervening cause. Id. at 76. In particular, CSI argues that, "[h]ad the jury accepted that Empire was an innocent participant and that River was the true culprit, the [intervening cause] instructions properly directed the jury to award only damages caused by it." Id. at 77.
Contrary to CSI's arguments, we conclude that the district court's instructions, considered as a whole, were not the "functional equivalent" of the apportionment of fault instructions specifically required by § 13-21-111.5(1). The district court's general instruction to the jury on assessing damages in connection with Empire's false representations gave the jury no room for apportioning fault among Empire and other entities. Although it is true that the court instructed the jury not to "take into account any other claims asserted by CSI against any other defendant," Joint App. at 7787, that instruction did not allow the jury to consider whether River was partially responsible for the injuries sustained
CSI has asserted one additional argument that requires mention. Less than a week prior to oral argument in this case, CSI filed a notice of supplemental authority citing
Town of Alma v. Azco Constr., Inc.,
Having concluded that Empire was prejudiced by the district court’s failure to give an apportionment of fault instruction, we reverse the damage award in favor of CSI on its fraudulent misrepresentation claim against Empire and remand the issue of CSI’s damages to the district court for further proceedings. 6
Sufficiency of evidence — 'punitive damages
Empire contends there was insufficient evidence to support the jury’s punitive damage award on CSI’s fraudulent misrepresentation claim. We will not address this argument since we are reversing the damage award entered in favor of CSI on its fraudulent misrepresentation claim and remanding for further proceedings.
Meridian’s Appeal (Case No. 00-1029)
Sufficiency of evidence — breach of warranty claims
Meridian contends the evidence presented at trial was insufficient to support the jury’s verdict on Bangert’s breach of express and implied warranty claims. ‘When a jury verdict is challenged on appeal, our review is limited to determining whether the record — viewed in the light most favorable to the prevailing party-— contains substantial evidence to support the jury’s decision.”
United Int’l Holdings, Inc. v. Wharf (Holdings) Ltd.,
With respect to Bangert’s claim against Meridian for breach of implied warranty of merchantability, the district court instructed the jury, without objection from Meridian, that it must find the following elements for Bangert to prevail:
1. Meridian sold the sand and rock aggregates for use on the F-111B Project;
2. Bangert [wa]s an entity ... reasonably expected to use the sand and rock aggregates;
3. Meridian was a merchant with respect to the type of product involved herein;
4. The sand and rock aggregates were not of merchantable quality at the time of sale;
5. This breach of warranty caused Bangert damages; and
6. Within a reasonable time after the alleged breach of warranty was discovered or should have been discovered, Bangert gave notice to Meridian or Meridian received notice of such breach.
Joint App. at 7611. We construe Meridian’s appellate pleadings as challenging only two of these elements. First, Meridian challenges the sufficiency of the evidence on the fourth element, asserting
With regard to the merchantable quality issue, we conclude that the record contains substantial evidence to support the jury’s verdict. Several witnesses involved in the project testified they personally observed clay in the sand stockpile at the job site. Tr. at 558, 657 (Henry Bangert), 2715, 2853 (Daniel DeGraaf), 2902-03, 2985 (Jerry Camper), 3057 (Douglas Logue), 4686 (Douglas Ruder). One witness, Kiewit employee Jerry Camper, testified that, throughout the course of the project, he personally observed clayballs in the sand being delivered to the project site. Id. at 2902-03, 2985. Another Kiew-it employee, Daniel DeGraaf, testified that on one occasion Kiewit decided to return an amount of dirty sand to Meridian so that it could be washed properly. Id. at 2715; see also id. at 4686 (testimony of Douglas Ruder supporting DeGraaf s testimony). DeGraaf further testified that he and CSI owner Steve Chaves drove to the sand pit where Meridian’s sand originated and informed Meridian that its sand would have to be washed before being shipped to the project site. Id. at 2717. Taken together, this evidence was adequate to support the jury’s finding that the sand provided by Meridian for the project was not of merchantable quality.
Similarly, several witnesses testified that the rock delivered by Meridian to the project site was dirty and required rewashing before it could be used in the concrete batching process. 7 For example, Henry Bangert, the vice president in charge of construction for plaintiff Bangert, testified that his company concluded that the rock provided by Meridian was too dirty to use without being rewashed on-site. Tr. at 510. Steve Chaves, the owner of plaintiff CSI, testified that Meridian itself concluded the rock it had initially delivered to the project site was too dirty and needed to be rewashed. Id. at 4241. Taken together, this evidence was likewise adequate to support the jury’s finding that the rock supplied by Meridian to the project was not merchantable without being rewashed at the job site.
The remaining issue is whether there was sufficient evidence to allow the jury to find that the breaches of warranty caused Bangert damages. There was very little direct evidence indicating that the dirty sand provided by Meridian caused the clayball problems encountered by Bangert in late June and July of
As for the dirty rock, Bangert vice president Henry Bangert testified that the rewashing process implemented by the parties to deal with the problem greatly increased the amount of water and mud that was present on the job site. Tr. at 511, 556-57, 693. Bangert’s testimony on this point was bolstered by the testimony of Kiewit employee Jerry Camper, who testified that the stockpile areas were located in low-lying areas and did not drain properly. Id. at 2893. Henry Bangert further testified that these conditions increased the amount of mud. transferred from the loading equipment into the concrete batching process, thereby resulting in the clayball problems experienced by Bangert. Id. at 511. Considered together, this testimony was sufficient to support the jury’s finding that the breach of implied warranty injured Bangert.
With respect to Bangert’s claim against Meridian for breach of express warranty, the district court instructed the jury, without objection from Meridian, that it had to find the following elements in order for Bangert to prevail:
1. Meridian furnished sand and rock aggregates for use on the F-111B Project;
2. Meridian expressly warranted that the aggregates would comply with the Project’s specifications and would be properly washed and free from contamination;
3. Bangert [wa]s a company that Meridian reasonably expected to use the sand and rock aggregates;
4. The aggregates were not as warranted;
5. This breach of warranty caused Bangert damages; and
6. Within a reasonable time after the • • alleged breach of warranty was discovered or should have been discovered, Bangert gave notice to Meridian or Meridian received notice of such breach.
Joint App. at 7623.
Meridian does not raise any additional arguments with regard to this claim. Instead, Meridian argues, as it did with the breach of implied warranty claim, there was insufficient evidence to prove (1) the rock and sand were contaminated, and (2)
Foreseeability of consequential damages
Meridian contends it should not be held liable for the clayball damages incurred by Bangert because those damages were not a reasonably foreseeable consequence of the alleged breaches of warranty. Meridian’s contention is based on two related points. First, Meridian asserts “there was absolutely no evidence that the materials [it] supplied ... were contaminated with clayballs/mud at the point of delivery.” Meridian’s Opening Br. at 18. Second, and relatedly, Meridian contends that “the only theory upon which Bangert might rest its warranty claims ... is that Meridian delivered two train loads of dirty rock.” Id. at 18-19. Meridian asserts that “clayball contamination does not ordinarily and naturally flow from dirty rock.” Id. at 20. Instead, Meridian asserts that any increased mud on the project site was the result of Kiewit’s preparation of the batch site and CSI’s operation of the rock-washing equipment.
As Bangert correctly notes, Meridian did not raise this issue in district court. Although Meridian suggests that it preserved the issue by moving for judgment as a matter of law on the general grounds “that Bangert had not introduced evidence to support the negligence and warranty claims against it,” Meridian’s Reply Br. at 8, it is apparent from reviewing the record on appeal that nothing in Meridian’s arguments at trial alerted the district court to the fact that Meridian was challenging the foreseeability of damages.
See Vanderhurst v. Colorado Mountain Coll. Dist.,
Damages — proximate cause
Meridian contends that Bangert should be precluded from recovering any damages for the clayball problem because Bangert was aware of clayball contamination in the sand prior to, or at least during, the initial paving operations. As with the previous issue, there is no indication in the record that Meridian presented this argument to the district court and Meridian has waived it for purposes of appeal. Even overlooking the waiver, we note that Meridian was able to present evidence and argument at trial that Bangert failed to mitigate its damages (e.g., by stopping paving operations). Because the jury considered and rejected the mitigation of damages argument, Meridian has no basis for appeal.
Instructions — Meridian’s counterclaim under CPWA
Meridian contends the district court failed to properly instruct the jury regarding its counterclaim against Bangert under the CPWA,. Colo.Rev.Stat. § 38-26-105, which creates a remedy designed to protect suppliers of labor and material for
Meridian has waived any error arising out of the district court’s failure to instruct the jury regarding privity, or the lack thereof, between Bangert and Meridian. As noted by Bangert, there is no indication in the record that Meridian submitted a proposed instruction discussing the privity issue, nor is there any indication in the transcript that Meridian’s counsel raised the privity issue during the formal instruction conference. Therefore, Meridian is precluded from raising the issue for the first time on appeal.
See Allison,
We conclude there is no merit to Meridian’s remaining argument.
9
In instructing the jury with regard to Meridian’s claim under the CPWA, the district court stated, in pertinent part, that it was necessary for Meridian to prove by a preponderance of the evidence that it “supplied materials used in the prosecution of the work on Project F-111B.” Joint App. at' 7812. This language was derived directly from the CPWA, which provides that a contractor on a public works project “shall at all times promptly make payments of all amounts lawfully due to all persons supplying or furnishing such person or such person’s subcontractors with ... materials ... used ... in the prosecution of the work.” Colo.Rev.Stat. § 38-26-105(1)., Although “[i]t is true that the recitation of statutory language [in a jury instruction] does not preclude a finding of error,”
Summers v. Missouri Pacific R.R. Sys.,
Prejudgment interest—accrual date
Plaintiff Bangert contends the district court erred in establishing the accrual date for prejudgment interest on its compensatory damages against Meridian. According to Bangert, it was entitled to prejudgment interest accruing from the date of Meridian’s wrongful conduct rather than the date of the triabas established by the district court. Prejudgment interest questions in diversity cases are governed by state law.
Atlantic Richfield Co. v. Farm Credit Bank of Wichita,
Under Colorado law, a prevailing party is entitled to prejudgment interest “[w]hen money or property has been wrongfully withheld.” Colo.Rev.Stat. § 5-12-102(1)(a). Colorado law further provides that the prejudgment “interest shall be an amount which fully recognizes the gain or benefit realized by the person withholding such money or property from the date of wrongful withholding to the date of payment or to the date judgment is entered, whichever first occurs.”
Id.
We previously have held that Colorado’s prejudgment interest statute operates in favor of victims of tortious conduct.
See United Int'l,
Although the district court concluded that Bangert was entitled to prejudgment interest under Colorado law, it awarded such interest only from the first day of trial, September 8, 1998, until the date judgment was entered. Joint App. at 4106-07. In doing so, the district court noted that Bangert presented evidence to the jury in the form of Exhibit 583A, which listed Bangert’s alleged damages and included interest on the damages from January 1,1994, to the first day of trial. Id. at 4106. The district court further noted that the jury was instructed to fully compensate Bangert for the damages it incurred. Id. at 4107. Based on these factors, the district court “presumed that the jury followed their charge” and included prejudgment interest in its damage award. Id. Thus, the district court concluded that awarding prejudgment interest to Bangert from the date of its wrongful conduct would result in a double-recovery of interest (or at least a partial double-recovery) for Bangert.
Although Bangert acknowledges that its exhibit 583A included interest' calculations, it offers several reasons why this was an insufficient basis for the district court’s decision. First, Bangert points out that “[n]o one objected to that exhibit on that ground.” Bangert’s Amended Reply Br. at 5. Second, Bangert notes that it “promptly corrected the situation, and later damages exhibits did not include interest.”
Id.
Third, “[n]either of Bangert’s damages experts included interest in his analysis.”
Id.
Fourth, “Bangert did not ask the jury to award any interest” during closing arguments, and Meridian’s counsel told the jury during closing arguments that the calculated interest had been stricken from Bangert’s claim and the jury could “forget” interest.
10
Id.
Fifth, Bangert notes that the district court did not in
Reviewing the issue de novo, we conclude the district court erred in presuming that the jury’s verdict necessarily included an award of prejudgment interest. Although one of Bangert’s exhibits referred to interest on damages, Bangert’s damage experts did not discuss that element of damages in their testimony, nor did Ban-gert’s counsel ask for an award of interest during closing arguments. Indeed, as noted above, Meridian’s counsel stated to the jury during closing argument, without objection from Bangert’s counsel, that the interest computations on Exhibit 583A had been stricken and were no longer to be considered by the jury. Further, the jury instructions were silent with respect to the issue of prejudgment interest and there was nothing in the instructions to require the jury to include an interest component in its damage award. Finally, nothing about the amount of damages awarded by the jury necessarily indicates that the jury included prejudgment interest in its award. Considered together, these factors clearly weigh against any presumption that the jury included prejudgment interest in its damage award.
See Gierlinger v. Gleason,
In light of this conclusion, we reverse the prejudgment interest award in favor of Bangert and against Meridian, and remand with instructions to the district court to award prejudgment interest in favor of Bangert accruing from January 1, 1994.
Meridian’s quantum meruit claim
Bangert contends the district court erred in entering judgment in favor
In
Skinner v. Total Petroleum, Inc.,
The Seventh Amendment protects a party’s right to a jury trial by ensuring that factual determinations made by a jury are not thereafter set aside by the court, except as permitted under the common law.... Thus, under the Seventh Amendment, the court may not substitute its judgment of the facts for that of the jury; it may only grant a new trial if it concludes that the jury’s verdict was so against the weight of the evidence as to be unsupportable.
The strictures of the Seventh Amendment are particularly applicable in a case where, due to the presence of both equitable and legal issues, trial is both to the jury and to the court. In such a situation, when a case involves both a jury trial and a bench trial, any essential factual issues which are central to both must be first tried to the jury, so that the litigants’ Seventh Amendment jury trial rights are not foreclosed on common factual issues. Moreover, the court is bound by the jury’s determination of factual issues common to both the legal and equitable claims.
(Internal citations omitted.)
In order to preserve Bangert’s Seventh Amendment rights, we must treat the jury’s verdict on Meridian’s CPWA counterclaim (which verdict the district court allowed to stand) “as binding under collateral estoppel or issue preclusion principles.”
Ag Serv. of America, Inc. v. Nielsen,
The jury was instructed that, in order to find for Meridian on its CPWA claim, Meridian had to prove beyond a preponderance of the evidence' that: (1) “Meridian supplied materials used in the prosecution of the work on Project F-111B,” (2) “[n]either Bangert nor any other party made full payment to Meridian for the materials supplied,” and (3) “[t]he monies claimed by Meridian [we]re lawfully due to Meridian.” Joint App. at 7812. Because the verdict form on the CPWA claim was a general one, simply asking the jury whether or not it found in favor of Meridian and against
To resolve the issue, we turn to the record on appeal. The central point of dispute between Meridian and Bangert at trial (with respect to Meridian’s counterclaims) was the amount of materials (i.e., sand and rock) actually supplied by Meridian to the project. Meridian asserted that it had not been paid fully for all .materials it shipped to the project site. In support of its assertion, Meridian relied on its shipping and billing records, which it argued were reliable and trustworthy. Meridian also asserted (without dispute from Ban-gert) that it was unnecessary for it to demonstrate that the materials it allegedly delivered to the project site were actually incorporated into the concrete runway (as opposed to being wasted by Ban-gert/CSI/Kiewit or used for other purposes on the job site). Tr. at 7492.
Bangert’s position was that it had paid Meridian fully for materials actually supplied to the project. More specifically, Bangert asserted that Meridian’s shipping/billing records were flawed, and that at least some of the materials for which Meridian sought payment actually were used on another runway project at DIA with which it had no involvement. • Consistent with this position, Bangert’s counsel made the following statements to the jury during closing arguments:
Meridian is pursuing Bangert under the Public Works Act, and under the Public Works Act you have to show that the materials were used in the prosecution of the work.... The point is, they [Meridian] had to show, and they didn’t show, that those materials [i.e., the sand and rock for which Meridian sought payment] were used in the prosecution of the work. And that’s the quantity dispute, ladies and gentlemen.
Tr. at 7566 (rebuttal argument from Ban-gert’s counsel). In addition, Bangert’s counsel stated to the jury: “[W]e believe Meridian has substantially overbilled for the rock that they allege was used on the job.” Id. at 7568.
Given the parties’ positions, as well as the evidence presented by the parties to support their respective positions, it is apparent that the jury’s resolution of Meridian’s CPWA claim rested on the second element of the claim. In short, the only issue of dispute was whether Meridian had been paid fully for the materials it actually supplied for the F-111B project.
12
In finding in favor of Bangert and against
The question then becomes whether the jury’s factual finding on this point precluded the district court from finding in favor of Meridian on its quantum meruit claim. Under Colorado law, a plaintiff seeking to recover under a theory of quantum meruit, or unjust enrichment, must establish that “(1) at plaintiffs expense (2) defendant received a benefit (3) under circumstances that would make it unjust for defendant to retain the benefit without paying.”
Salzman v. Bachrach,
III.
With respect to Empire’s appeal (Case No. 00-1024), we AFFIRM the judgment as a matter of law in favor of CSI on its fraudulent misrepresentation claim, but REVERSE the damage award in favor of CSI on its fraudulent misrepresentation claim and REMAND to the district court for further proceedings consistent with this order. With respect to Meridian’s appeal (Case No. 00-1029), we AFFIRM the judgment of the district court. With respect to Bangert’s appeal (Case No. 00-1036), we REVERSE the district court’s prejudgment interest award in favor of Bangert on its claims against Meridian and REMAND with directions to the district court to award prejudgment interest in favor of Bangert on that claim from January 1, 1994, to the date of the original judgment. We also REVERSE the judgment of the district court in favor of Meridian on its quantum meruit counterclaim against Bangert.
Notes
. The precise nature of the agreements among Bangert, CSI, and Kiewit regarding their respective duties on the project was a significant area of dispute during the proceedings in district court. However, because those claims have now been settled, it is unnecessary to discuss them in detail.
. Federal Aviation Administration specifications for the project required that any mix-design had to be tested by an independent laboratory before paving began. Kiewit selected Empire as the independent testing laboratory for its mix-designs.
. The testing was performed on a “Rainhart machine,’’ which is used to determine the flexural strength of concrete beams. Tr. at 1864. The machine graphically records, on a piece of paper called a “Rainhart wheel,” the pressure per square inch a concrete beam can withstand before it breaks. Id. As increasing pressure is applied to a beam by the machine, a red-ink marker records the pressure on the Rainhart wheel. When the beam breaks, the red line automatically stops at the point showing the maximum pressure applied. Here, the Empire technicians physically extended the red ink lines on many Rainhart wheels, falsely suggesting the beams were stronger than they were.
. "The elements of fraud [under Colorado law] are: (1) a false representation of a material existing fact; (2) knowledge on the part of the one making the representation that it was false; (3) ignorance on the part of the one to whom the representation was made of its falsity; (4) the representation was made with an intention that it be acted on; and (5) the representation resulted in damage.”
Southeastern Colo. Water Conservancy Dist. v. Cache Creek Mining Trust,
. The district court's "intervening cause” instruction stated, in pertinent part, as follows:
If more than one cause contributed to CSI’s claimed damages, then each may have been a cause of the damages.
It is not necessary that CSI prove that the alterations were the sole and exclusive cause of the alleged damages, or the latest cause. What CSI must prove by a preponderance of the evidence is that the alterations of the test results were a significant cause, without which the damages would not have occurred. This requires a showing that the alterations of the test results were a "but for” cause of CSI's alleged damages.
In making that determination, the jury must take into account the foreseeability of the damages and whether any other independent cause or causes, not related to the alteration of the test results and not reasonably foreseeable, intervened after the alterations and were a significant cause of CSI's damages.
If Empire has proved by a preponderance of the evidence that other conduct not reasonably foreseeable intervened after the alterations of the test results and caused the alleged damages, then the jury cannot return a verdict for any amounts of damages caused by such intervening causes.
Joint App. at 7789.
. Our holding does not affect the district court’s partial grant of judgment as a matter of law in favor of CSI and against Empire.
. In its response brief, Bangert contends "[t]he jury was not required to make separate findings or issue separate verdicts for breach of warranty regarding contaminated rock on the one hand, and contaminated sand on the other.” Bangert's Response Br. at 103. "Thus,” Bangert argues, it "need only show a basis in the record supporting breach of warranty on one of these products.” Id. Although Bangert’s argument seems reasonable at first blush, it is not consistent with the district court's jury instructions, which stated that the jury had to find that "[t]he sand and rock aggregates were not of merchantable quality at the time of sale.” Joint App. at 7611 (emphasis added).
. Kiewit employee Jerry Camper arguably provided direct testimony linking the sand contamination to the clayball problems experienced by Bangert during the initial course of paving. In particular, Camper pointed to the sand contamination as one of four specific causes of the clayball problem. Tr. at 2902-OS. On cross-examination, however, Camper stated that the dirty sand would not have caused the clayball problem. Id. at 2965.
. Meridian has made review of this argument difficult by failing to include in the record on appeal a copy of the proposed jury instruction(s) it submitted to the district court on its CPWA counterclaim, and by failing to cite the portions of the transcript where the district court ruled on its argument. We have conducted an independent review of the trial transcript and note there was a brief discussion of the issue during the formal instruction conference (but the discussion also suggests there was a more complete discussion at an earlier, untranscribed instruction conference). Tr. at 7804.
. During closing arguments, Meridian’s lead counsel specifically discussed the damages exhibit to which the district court referred and stated: "We can start out—because after it
. Bangert also argues that neither the evidence in the record nor the district court's findings of fact support a claim for unjust enrichment under Colorado law. We find it unnecessary to address this argument since we agree with Bangert that the district court’s judgment on the quantum meruit claim is inconsistent with the jury’s verdict on the CPWA claim.
. The first element was not at issue since it was uncontroverted that Meridian supplied