Baerveldt Construction Co. v. Bagley

231 Mo. 157 | Mo. | 1910

VALLIANT, J.

Plaintiff, a corporation, sued in two counts to recover a balance claimed to be due it for labor and materials which entered into the construction of a certain building, under a contract with the defendant Bagley, and to establish a mechanic’s lien on the building: the first count was a declaration on quantum meruit, the second on the contract. The balance claimed in the petition is $7038.52 with interest from September 15, 1904, when it became due and demand was made. The suit was begun January 17, 1905; the judgment was rendered June 8, 1906. The cause was tried by the court, jury waived; the finding and judgment were for the defendants and the plaintiff appealed. It is unnecessary to set out the pleadings, as no point on that phase of the case is made, and the points in controversy will sufficiently appear from a statement of the facts. No instructions were ashed or given. The plaintiff filed its claim for a mechanic’s lien in due time and due form. There is but little, if any, dispute as to the principal facts in the ease.

The land on which the building was to be erected was owned by defendant Bagley. The contract price of the building, when completed according to specifications, was $28,913.75. The building was completed and delivered to Bagley, in all respects according to the contract, except that it was not completed within the time specified. It was specified that for every day of delay in the completion beyond the date named the contractor should pay twenty dollars as liquidated damages. At that rate there was delay enough to make the sum to be so paid amount to eighteen hundred dollars and the defendant Bagley in his answer claimed that amount as a counterclaim or off-set, but the evidence showed justifiable cause for the delay, therefore the court found against him on that item; the judgment to that extent was for the plaintiff, and no appeal was taken by defendant.

During.the progress of construction there was paid to the plaintiff sums aggregating $21,875.23, leaving a balance of $7038.32 to be settled. The contract required the plaintiff to pay for all the labor and materials employed and used by Mm in the building so as to protect it against mechanics’ liens, but he allowed bills.of that kind to accumulate to the amount of $3515.30 and liens for such bills to be filed. These bills defendant Bagley paid and was therefore entitled to recover that sum of plaintiff or deduct it from the balance due plaintiff, if there was such balance. Bagley set up a counterclaim for that sum.

At the time of entering into the building contract the parties made another agreement in writing whereby defendant Bagley was to convey to plaintiff, or to whom plaintiff might designate, certain real estate on Page Avenue in. the city which the plaintiff was to receive, at the agreed valuation of $6,800, in payment to that extent on the price of the building contract. A deed in due form was made by Bagley and wife to Johanna Baerveldt, the person for that purpose designated by the plaintiff, and was, by agreement of the parties, placed in the hands of the Maguire Real Estate Company to be delivered to the grantee when the plaintiff completed its contract.

By the terms of the second agreement it was specified: “that the consideration in said deed being $11,800, less an existmg deed of trust, for $5000 on said property, leaving an equity of $6800, which $6800 is accepted as a cash payment on contract,” etc. — the building contract above mentioned.

There is this difference between the recitals in the deed and those in the agreement, namely: in the deed it is specified that the property is conveyed with covenants of warranty of title “except as against taxes, special and general, for the year 1904, and a certain deed of trust on lots 19 to 23 inclusive to secure payment of five thousand dollars wMch the said party of the second part [Johanna Baerveldt] covenants and assumes to pay as a part of the consideration of this deed,” whereas in the agreement there is no mention of taxes. The deed had been drawn, signed and acknowledged before the execution of the agreement and Mr. Baerveldt testified that he objected to the mention of taxes therein, and that the written agreement, specifying only the five thousand dollar deed of trust to be assumed by the grantee, was so worded to comply with. his objection. Plaintiff offered in evidence a certificate of title from a title examiner which showed that certain taxes for the year 1904 were delinquent, but on objection by the defendants the offer was withdrawn, and the certificate was not afterwards introduced in-evidence, otherwise than it was attached as an exhibit to the plaintiff’s motion for a new trial.

After the building was completed the plaintiff demanded of the Maguire Real Estate Company the deed held by it in escrow, but that company refused to deliver it then because of the unpaid bills for labor and materials above mentioned, which bills Bagley after-wards paid. After that, how long after is not shown, the ■ Page avenue land described in the deed- held by the Maguire Real Estate Company, or that, part of it which was covered by the five thousand dollar deed of trust, was sold under foreclosure of the trust and the title passed to a stranger.

The court found that the contract price -of the building was $28,913.75, on which plaintiff ha,d been paid $21,875.23, leaving unpaid in cash $7038.52, against which plaintiff was chargeable with the agreed price of the land covered by the deed in escrow, $6800, leaving due him $238.52. That there was due the defendant Bagley $3515.30 for the bills for labor and material above mentioned less the $238.52, balance due plaintiff, leaving $3276,78.

The judgment was that plaintiff was not entitled to a mechanic’s lien, that he should recover nothing on the first count of his petition, that Bagley recover nothing on his counterclaim for delay, but that he recover of plaintiff on his counterclaim for labor and materials paid by him the sum of $3276.78 and have execution therefor and a lien for the same on the Page Avenue property described in the escrow, which lien should be prior to any title created by that deed; that the Maguire Real Estate Company deliver' to plaintiff or into court for plaintiff the deed so held in escrow and then stand discharged; that the other defendants be discharged, and plaintiff pay the costs of the suit. Prom that judgment the plaintiff brings this appeal.

I. Perhaps before entering upon a consideration of the merits it is well to notice the facts bearing on the question of the jurisdiction of this court of the cause.

It is an action at law, ex contractu. Plaintiff in its petition states that there is a balance due it on the account of $7038.52, that it demanded payment September 15., 1904, and the prayer is for judgment for $7038.52 and interest from that date. The petition was filed January 17, 1905; the amount of the balance claimed, with interest to that date, would be less than $7500, but on the day the judgment was rendered, June 8, 1906, if the-plaintiff had recovered what he was then claiming, it would, counting interest to that date, have been $7770:42. But the judgment was that the plaintiff recover nothing on that claim, and the plaintiff is here by appeal from that judgment, claiming now that it-should have had judgment then for $7038.52 plus interest from September 14, 1904, to June 8, 1906, that is, $7770.42. That is, therefore, “the amount in dispute,” and therefore this court has jurisdiction of the cause.

In considering this subject of jurisdiction, as depending on'the amount in controversy, we observe a distinction between an action in tort, where the amount of damages claimed in the petition does not bear interest before judgment, and an action of this kind, where the amount claimed arises out of a contract, express or implied, and where the petition states facts constituting a- right to recover not only the amount specified as principal but also interest.

Schwyhart v. Barrett, 223 Mo. 497, was a suit to recover damages for personal injuries, and it was there said, l. c. 501: “If a plaintiff brings suit for damages and states in his petition the amount for which he sues, if he is cast in his suit and! appeals, we go back to the petition and say that the amount there claimed is the amount in dispute. If the plaintiff should in such case recover judgment for a certain amount and the defendant appeals, the amount then in dispute is the amount of the judgment. The date of the dispute in the one case is that of the filing of the petition, in the other it is that of the rendition of the judgment, and in either case the amount in dispute is the amount for which the dispute could at that date have been settled. If not settled then and interest is added, it is added by operation of law, not as a part of the amount in dispute, but as a consequence of withholding it. Interest in such case is a mere incident', a mere sequence.”

We call attention to the distinction to be observed in this particular between a case where interest does not run on the amount demanded in the petition and a case where it does run, lest what is said in Schwyhart v. Barrett might be construed as applying to a case of the kind at bar.

2. Appellant contends that defendant Bagley committed a breach of the contract by claiming damages for the delay, which claim was found by the court to be unsound, and that he, having attempted to impose on the plaintiff a deed to the Page Avenue property excepting from the warranty of title the taxes general and special for the year 1904, thereby again committed a breach of the contract, and therefore had no right to insist on the plaintiff’s accepting the deed in part payment of the contract, and that because of those breaches plaintiff had the right to refuse to accept the deed and to demand payment in money of the balance due on the contract, and was justified in allowing those who had filed liens to prosecute their liens to judgments, and then when those claims were paid by Bagley, the latter could deduct the amount of thfe same from the amount due plaintiff and pay it the balance.

Defendant Bagley cannot be adjudged to have committed a breach of the contract by making a claim for damages for the delay in finishing the building, although his claim was not allowed by the court. If he thought he was’ entitled to the liquidated damages called for by the contract he had a right to assert the claim, and even if he did' not think he was so entitled he committed no act in relation thereto that was detrimental to the plaintiff; he did not withhold the deed to the Page avenue property from plaintiff because of this claim for damages, but it was ‘withheld because of the plaintiff’s refusal to pay off the liens that were filed. The plaintiff was in duty bound to pay off those liens and was not entitled' to the deed then held in escrow while those liens were standing against the building.

Nor did the plaintiff suffer any wrong because of the language of the deed requiring him to pay the taxes, general and special, for the year 1904. Mr. Baerveldt read the deed before he signed the agreement to accept it in payment of $6800 on his contract, and he knew its contents. He testified that he objected to that clause in the deed, and' would not agree to accept it "until Mr. Bagley assured him that he would pay the taxes, and on that assurance he agreed to accept the deed in that form; therefore, he cannot claim to have been deceived as to its contents; if he was injured it was by the failure of the defendant Bagley to do what it is alleged he agreed to do in the way of paying taxes, and, as to that, there was no evidence of any breach of that promise,’ because there was no proof that there were any taxes then delinquent. Plaintiff offered in evidence a certificate of a professional title examiner indicating that there were taxes delinquent on the property for the year 1904, but the evidence was so clearly incompetent that when objection was made it was withdrawn, and there was no other evidence on that point offered. It does not appear in the record that the plaintiff, before the parties assumed hostile attitudes towards each other or before this suit was brought, ever brought the subject of the alleged promise to pay the taxes to the notice of defendant Bagley or insisted that the taxes be paid. Besides, according to the plaintiff’s own showing, it demanded the deed of the Maguire Real Estate Company when the building was finished, well knowing then its contents, and was willing then to take it at the agreed price without making any point in regard to taxes. But at that time • the plaintiff was not entitled to the deed, because, although there was a balance of $7038.52 unpaid on the building contract, yet against that balance there was the aggregate sum of $3515.30 of the mechanics’ liens filed, which the plaintiff was leaving for defendant Bagley to pay, and which when paid would leave the balance due plaintiff only $3523.22, instead of $6800, the agreed price of the Page Avenue property. He was therefore at that time not entitled to the deed to the property. If since then the title to the property has passed to a stranger, it is because the plaintiff did not take care of the five thousand dollar deed of trust. which it was agreed the grantee in the deed should assume. If the grantee had paid the five thousand dollar mortgage, she would now, under the terms of the judgment appealed from, be entitled to the Page Avenue property, agreed to be worth $11,800, against which would stand the amount the plaintiff owes defendant Bagley, $3276.78.

The trial judge had the right conception of the right and justice of the cause. The judgment is affirmed.

All concur.